e10vq
UNITED STATES
SECURITIES AND EXCHANGE COMMISSION
Washington, D.C. 20549
FORM 10-Q
QUARTERLY REPORT PURSUANT TO SECTION 13 OR 15(d) OF THE
SECURITIES EXCHANGE ACT OF 1934
For the quarterly period ended June 30, 2005
Commission File No 0-25428
MEADOW VALLEY CORPORATION
(Exact name of registrant as specified in its charter)
|
|
|
Nevada
|
|
88-0328443 |
(State or other Jurisdiction of
|
|
(I.R.S. Employer Identification Number) |
incorporation or organization) |
|
|
4411
South 40th Street, Suite D-11
Phoenix, Arizona 85040
(602) 437-5400
Indicate by check mark whether the registrant (1) has filed all reports required to be filed by
Section 13 or 15(d) of the Securities and Exchange Act of 1934 during the preceding 12 months (or
for such shorter period that the registrant was required to file such reports), and (2) has been
subject to such filings requirements for the past 90 days. Yes þ No o
Indicate by check mark whether the registrant is an accelerated filer (as defined in Rule 12b-2 of
the Act). Yes o No þ
Number of shares outstanding of each of the registrants classes of common stock as of August 8,
2005:
Common Stock, $.001 par value
3,683,130 shares
MEADOW
VALLEY CORPORATION
INDEX
REPORT ON FORM 10-Q
FOR THE QUARTER ENDED JUNE 30, 2005
2
PART I FINANCIAL INFORMATION
Item 1. Financial Statements
MEADOW VALLEY CORPORATION AND SUBSIDIARIES
CONDENSED CONSOLIDATED BALANCE SHEETS
|
|
|
|
|
|
|
|
|
|
|
June 30, |
|
December 31, |
|
|
2005 |
|
2004 |
|
|
(Unaudited) |
|
|
|
|
Assets: |
|
|
|
|
|
|
|
|
Current Assets: |
|
|
|
|
|
|
|
|
Cash and cash equivalents |
|
$ |
5,297,657 |
|
|
$ |
10,164,218 |
|
Restricted cash |
|
|
1,560,751 |
|
|
|
1,268,449 |
|
Accounts receivable, net |
|
|
26,935,297 |
|
|
|
22,163,719 |
|
Prepaid expenses and other |
|
|
2,236,771 |
|
|
|
2,818,395 |
|
Inventory, net |
|
|
961,147 |
|
|
|
871,112 |
|
Costs and estimated earnings in excess of billings on uncompleted
contracts |
|
|
1,793,978 |
|
|
|
449,358 |
|
Deferred tax asset |
|
|
894,201 |
|
|
|
1,597,627 |
|
|
|
|
|
|
|
|
|
|
Total Current Assets |
|
|
39,679,802 |
|
|
|
39,332,878 |
|
Property and equipment, net |
|
|
21,614,623 |
|
|
|
21,541,946 |
|
Refundable deposits |
|
|
56,228 |
|
|
|
21,780 |
|
Mineral rights and pit development, net |
|
|
263,122 |
|
|
|
252,044 |
|
Claims receivable |
|
|
3,521,080 |
|
|
|
3,521,080 |
|
Other receivables |
|
|
115,000 |
|
|
|
115,000 |
|
|
|
|
|
|
|
|
|
|
Total Assets |
|
$ |
65,249,855 |
|
|
$ |
64,784,728 |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Liabilities and Stockholders Equity: |
|
|
|
|
|
|
|
|
Current Liabilities: |
|
|
|
|
|
|
|
|
Accounts payable |
|
$ |
18,526,441 |
|
|
$ |
19,711,571 |
|
Accrued liabilities |
|
|
4,699,148 |
|
|
|
4,907,554 |
|
Notes payable |
|
|
4,911,702 |
|
|
|
5,212,187 |
|
Obligations under capital leases |
|
|
530,259 |
|
|
|
531,746 |
|
Billings in excess of costs and estimated earnings on uncompleted
contracts |
|
|
9,993,535 |
|
|
|
7,219,762 |
|
|
|
|
|
|
|
|
|
|
Total Current Liabilities |
|
|
38,661,085 |
|
|
|
37,582,820 |
|
Notes payable, less current portion |
|
|
9,063,221 |
|
|
|
10,804,017 |
|
Obligations under capital leases, less current portion |
|
|
712,598 |
|
|
|
981,799 |
|
Deferred tax liability |
|
|
3,243,268 |
|
|
|
3,243,268 |
|
|
|
|
|
|
|
|
|
|
Total Liabilities |
|
|
51,680,172 |
|
|
|
52,611,904 |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Commitments and contingencies |
|
|
|
|
|
|
|
|
Stockholders Equity: |
|
|
|
|
|
|
|
|
Preferred stock $.001 par value; 1,000,000 shares authorized, none
issued and outstanding |
|
|
|
|
|
|
|
|
Common stock $.001 par value; 15,000,000 shares authorized, 3,665,697
and 3,601,250 issued and outstanding |
|
|
3,666 |
|
|
|
3,601 |
|
Additional paid-in capital |
|
|
11,090,184 |
|
|
|
10,943,569 |
|
Capital adjustments |
|
|
(799,147 |
) |
|
|
(799,147 |
) |
Retained earnings |
|
|
3,274,980 |
|
|
|
2,024,801 |
|
|
|
|
|
|
|
|
|
|
Total Stockholders Equity |
|
|
13,569,683 |
|
|
|
12,172,824 |
|
|
|
|
|
|
|
|
|
|
Total Liabilities and Stockholders
Equity |
|
$ |
65,249,855 |
|
|
$ |
64,784,728 |
|
|
|
|
|
|
|
|
|
|
The accompanying notes are an integral part of these condensed consolidated financial statements.
3
MEADOW VALLEY CORPORATION AND SUBSIDIARIES
CONDENSED CONSOLIDATED STATEMENTS OF OPERATIONS
(Unaudited)
|
|
|
|
|
|
|
|
|
|
|
Six Months Ended |
|
|
June 30, |
|
|
2005 |
|
2004 |
Revenue: |
|
|
|
|
|
|
|
|
Construction services |
|
$ |
62,059,325 |
|
|
$ |
54,435,737 |
|
Construction materials |
|
|
31,309,690 |
|
|
|
28,441,115 |
|
|
|
|
|
|
|
|
|
|
Total revenue |
|
|
93,369,015 |
|
|
|
82,876,852 |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Cost of revenue: |
|
|
|
|
|
|
|
|
Construction services |
|
|
59,625,931 |
|
|
|
53,223,454 |
|
Construction materials |
|
|
28,158,422 |
|
|
|
25,586,901 |
|
|
|
|
|
|
|
|
|
|
Total cost of revenue |
|
|
87,784,353 |
|
|
|
78,810,355 |
|
|
|
|
|
|
|
|
|
|
Gross profit |
|
|
5,584,662 |
|
|
|
4,066,497 |
|
|
General and administrative expenses |
|
|
3,812,024 |
|
|
|
3,092,056 |
|
|
|
|
|
|
|
|
|
|
|
Income from operations |
|
|
1,772,638 |
|
|
|
974,441 |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Other income (expense): |
|
|
|
|
|
|
|
|
Interest income |
|
|
236,962 |
|
|
|
45,979 |
|
Interest expense |
|
|
(183,628 |
) |
|
|
(195,314 |
) |
Other income (expense) |
|
|
127,433 |
|
|
|
(66,564 |
) |
|
|
|
|
|
|
|
|
|
|
|
|
180,767 |
|
|
|
(215,899 |
) |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Income before income taxes |
|
|
1,953,405 |
|
|
|
758,542 |
|
|
|
|
|
|
|
|
|
|
Income tax expense |
|
|
(703,226 |
) |
|
|
(283,442 |
) |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Net income |
|
$ |
1,250,179 |
|
|
$ |
475,100 |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Basic net income per common share |
|
$ |
0.34 |
|
|
$ |
0.13 |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Diluted net income per common share |
|
$ |
0.31 |
|
|
$ |
0.13 |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Basic weighted average common shares outstanding |
|
|
3,629,028 |
|
|
|
3,601,250 |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Diluted weighted average common shares outstanding |
|
|
4,000,210 |
|
|
|
3,739,844 |
|
|
|
|
|
|
|
|
|
|
The accompanying notes are an integral part of these condensed consolidated financial statements.
4
MEADOW VALLEY CORPORATION AND SUBSIDIARIES
CONDENSED CONSOLIDATED STATEMENTS OF OPERATIONS
(Unaudited)
|
|
|
|
|
|
|
|
|
|
|
Three Months Ended |
|
|
June 30, |
|
|
2005 |
|
2004 |
Revenue: |
|
|
|
|
|
|
|
|
Construction services |
|
$ |
36,112,492 |
|
|
$ |
28,858,151 |
|
Construction materials |
|
|
17,330,510 |
|
|
|
14,849,968 |
|
|
|
|
|
|
|
|
|
|
Total revenue |
|
|
53,443,002 |
|
|
|
43,708,119 |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Cost of revenue: |
|
|
|
|
|
|
|
|
Construction services |
|
|
34,543,158 |
|
|
|
28,757,428 |
|
Construction materials |
|
|
15,261,292 |
|
|
|
13,348,169 |
|
|
|
|
|
|
|
|
|
|
Total cost of revenue |
|
|
49,804,450 |
|
|
|
42,105,597 |
|
|
|
|
|
|
|
|
|
|
Gross profit |
|
|
3,638,552 |
|
|
|
1,602,522 |
|
|
General and administrative expenses |
|
|
2,156,410 |
|
|
|
1,419,537 |
|
|
|
|
|
|
|
|
|
|
|
Income from operations |
|
|
1,482,142 |
|
|
|
182,985 |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Other income (expense): |
|
|
|
|
|
|
|
|
Interest income |
|
|
59,199 |
|
|
|
34,032 |
|
Interest expense |
|
|
(91,832 |
) |
|
|
(111,028 |
) |
Other income (expense) |
|
|
109,373 |
|
|
|
(46,108 |
) |
|
|
|
|
|
|
|
|
|
|
|
|
76,740 |
|
|
|
(123,104 |
) |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Income before income taxes |
|
|
1,558,882 |
|
|
|
59,881 |
|
|
|
|
|
|
|
|
|
|
Income tax expense |
|
|
(561,198 |
) |
|
|
(21,444 |
) |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Net income |
|
$ |
997,684 |
|
|
$ |
38,437 |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Basic net income per common share |
|
$ |
0.27 |
|
|
$ |
0.01 |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Diluted net income per common share |
|
$ |
0.25 |
|
|
$ |
0.01 |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Basic weighted average common shares outstanding |
|
|
3,653,501 |
|
|
|
3,601,250 |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Diluted weighted average common shares outstanding |
|
|
4,040,282 |
|
|
|
3,742,934 |
|
|
|
|
|
|
|
|
|
|
The accompanying notes are an integral part of these condensed consolidated financial statements.
5
MEADOW VALLEY CORPORATION AND SUBSIDIARIES
CONDENSED CONSOLIDATED STATEMENTS OF CHANGES IN STOCKHOLDERS EQUITY
For the six months ended June 30, 2005
(Unaudited)
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Common Stock |
|
|
|
|
|
|
|
|
Number of |
|
|
|
|
|
|
|
|
|
|
|
|
Shares |
|
|
|
|
|
Paid-in |
|
Capital |
|
Retained |
|
|
Outstanding |
|
Amount |
|
Capital |
|
Adjustment |
|
Earnings |
Balance at January 1, 2005 |
|
|
3,601,250 |
|
|
$ |
3,601 |
|
|
$ |
10,943,569 |
|
|
$ |
(799,147 |
) |
|
$ |
2,024,801 |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Common stock issued on
exercise of options |
|
|
64,447 |
|
|
|
65 |
|
|
|
146,615 |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Net income for the six months
ended June 30, 2005 |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
1,250,179 |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Balance at June 30, 2005 |
|
|
3,665,697 |
|
|
$ |
3,666 |
|
|
$ |
11,090,184 |
|
|
$ |
(799,147 |
) |
|
$ |
3,274,980 |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
The accompanying notes are an integral part of these condensed consolidated financial statements.
6
MEADOW VALLEY CORPORATION AND SUBSIDIARIES
CONDENSED CONSOLIDATED STATEMENTS OF CASH FLOWS
(Unaudited)
|
|
|
|
|
|
|
|
|
|
|
Six Months Ended |
|
|
June 30, |
|
|
2005 |
|
2004 |
Increase (decrease) in cash and cash equivalents: |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Cash flows from operating activities: |
|
|
|
|
|
|
|
|
Cash received from customers |
|
$ |
90,071,024 |
|
|
$ |
86,496,611 |
|
Cash paid to suppliers and employees |
|
|
(90,277,031 |
) |
|
|
(81,762,258 |
) |
Interest received |
|
|
236,962 |
|
|
|
45,979 |
|
Interest paid |
|
|
(183,628 |
) |
|
|
(195,314 |
) |
Income taxes received |
|
|
200 |
|
|
|
824 |
|
|
|
|
|
|
|
|
|
|
Net cash provided by (used in) operating
activities |
|
|
(152,473 |
) |
|
|
4,585,842 |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Cash flows from investing activities: |
|
|
|
|
|
|
|
|
Decrease (increase) in restricted cash |
|
|
(292,302 |
) |
|
|
66,201 |
|
Proceeds
from sale of property and equipment |
|
|
219,902 |
|
|
|
565,387 |
|
Increase in mineral rights and pit development |
|
|
(39,612 |
) |
|
|
|
|
Purchase of property and equipment |
|
|
(1,655,675 |
) |
|
|
(1,895,429 |
) |
|
|
|
|
|
|
|
|
|
Net cash used in investing activities |
|
|
(1,767,687 |
) |
|
|
(1,263,841 |
) |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Cash flows from financing activities: |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Proceeds
from the issuance of common stock |
|
|
146,680 |
|
|
|
|
|
Proceeds from notes payable |
|
|
|
|
|
|
181,070 |
|
Repayment of notes payable |
|
|
(2,822,393 |
) |
|
|
(2,075,587 |
) |
Repayment of capital lease obligations |
|
|
(270,688 |
) |
|
|
(480,614 |
) |
|
|
|
|
|
|
|
|
|
Net cash used in financing activities |
|
|
(2,946,401 |
) |
|
|
(2,375,131 |
) |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Net increase (decrease) in cash and cash equivalents |
|
|
(4,866,561 |
) |
|
|
946,870 |
|
|
|
|
|
|
|
|
|
|
Cash and cash equivalents at beginning of period |
|
|
10,164,218 |
|
|
|
4,738,388 |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Cash and cash equivalents at end of period |
|
$ |
5,297,657 |
|
|
$ |
5,685,258 |
|
|
|
|
|
|
|
|
|
|
The accompanying notes are an integral part of these condensed consolidated financial statements.
7
MEADOW
VALLEY CORPORATION AND SUBSIDIARIES
CONDENSED CONSOLIDATED STATEMENTS OF CASH FLOWS (Continued)
(Unaudited)
|
|
|
|
|
|
|
|
|
|
|
Six Months Ended |
|
|
June 30, |
|
|
2005 |
|
2004 |
Increase (decrease) in cash and cash equivalents (Continued): |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Reconciliation of net income to net cash provided by
operating activities: |
|
|
|
|
|
|
|
|
Net income |
|
$ |
1,250,179 |
|
|
$ |
475,100 |
|
Adjustments to reconcile net income to net cash
provided by (used in) operating activities: |
|
|
|
|
|
|
|
|
Depreciation and amortization |
|
|
2,153,827 |
|
|
|
1,421,263 |
|
Loss on sale of property and equipment |
|
|
18,915 |
|
|
|
22,204 |
|
Deferred taxes, net |
|
|
703,426 |
|
|
|
284,266 |
|
Allowance for doubtful accounts |
|
|
101,914 |
|
|
|
(187,020 |
) |
Inventory allowance |
|
|
|
|
|
|
193,104 |
|
|
|
|
|
|
|
|
|
|
Changes in operating assets and liabilities: |
|
|
|
|
|
|
|
|
Accounts receivable |
|
|
(4,873,492 |
) |
|
|
(969,620 |
) |
Prepaid expenses and other |
|
|
581,624 |
|
|
|
504,280 |
|
Inventory |
|
|
(90,035 |
) |
|
|
149,363 |
|
Costs and estimated earnings in excess of billings on
uncompleted contracts |
|
|
(1,344,620 |
) |
|
|
187,520 |
|
Refundable deposits |
|
|
(34,448 |
) |
|
|
(18,393 |
) |
Claims receivable |
|
|
|
|
|
|
4,101,898 |
|
Accounts payable |
|
|
(1,185,130 |
) |
|
|
(1,607,152 |
) |
Accrued liabilities |
|
|
(208,406 |
) |
|
|
(315,292 |
) |
Billings in excess of costs and estimated earnings on
uncompleted contracts |
|
|
2,773,773 |
|
|
|
344,321 |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Net cash provided by (used in) operating activities |
|
$ |
(152,473 |
) |
|
$ |
4,585,842 |
|
|
|
|
|
|
|
|
|
|
The accompanying notes are an integral part of these condensed consolidated financial statements.
8
MEADOW VALLEY CORPORATION AND SUBSIDIARIES
NOTES TO CONDENSED CONSOLIDATED FINANCIAL STATEMENTS
1. Summary of Significant Accounting Policies and Use of Estimates:
Presentation of Interim Information:
The condensed consolidated financial statements included herein have been prepared by Meadow
Valley Corporation (we, us, our or Company) without audit, pursuant to the rules and
regulations of the United States Securities and Exchange Commission (SEC) and should be read in
conjunction with our Annual Report on Form 10-K for the year ended December 31, 2004 as filed with
the SEC under the Securities and Exchange Act of 1934. Certain information and footnote
disclosures normally included in financial statements prepared in accordance with accounting
principles generally accepted in the United States of America have been condensed or omitted, as
permitted by the SEC, although we believe the disclosures, which are made are adequate to make the
information presented not misleading. Further, the condensed consolidated financial statements
reflect, in the opinion of management, all normal recurring adjustments necessary to present fairly
our financial position at June 30, 2005 and the results of our operations and cash flows for the
periods presented. The December 31, 2004 consolidated balance sheet data was derived from audited
consolidated financial statements, but does not include all disclosures required by accounting
principles generally accepted in the United States of America.
Interim results are subject to significant seasonal variations and the results of operations
for the six months ended June 30, 2005 are not necessarily indicative of the results to be expected
for the full year.
Nature of Corporation:
Meadow Valley Corporation (the Company) was organized under the laws of the State of Nevada
on September 15, 1994. The principal business purpose of the Company is to operate as the holding
company of Meadow Valley Contractors, Inc. (MVCI) (Construction services segment) and Ready
Mix, Inc. (RMI) (Construction materials segment). MVCI is a general contractor, primarily
engaged in the construction of structural concrete highway bridges and overpasses, and the paving
of highways and airport runways for various governmental authorities, municipalities and developers
in the states of Nevada, Arizona and Utah. RMI manufactures and distributes ready-mix concrete in
the Las Vegas, Nevada and Phoenix, Arizona metropolitan areas.
Revenue and Cost Recognition:
Revenues and costs from fixed-price and modified fixed-price construction contracts are
recognized for each contract on the percentage-of-completion method, measured by the percentage of
costs incurred to date to the estimated total direct costs. Direct costs include, among other
things, direct labor, field labor, equipment rent, subcontracting, direct materials and direct
overhead. General and administrative expenses are accounted for as period costs and are,
therefore, not included in the calculation of the estimates to complete construction contracts in
progress. Project losses are provided for in their entirety in the period in which such losses are
determined, without reference to the percentage-of-completion. As contracts can extend over one or
more accounting periods, revisions in costs and earnings estimated during the course of the work
are reflected during the accounting period in which the facts that required such revision become
known.
We recognize revenue in our construction material segment on the sale of our concrete and
aggregate products at the time of delivery.
Claims Receivable:
Claims for additional contract revenue are recognized only to the extent that contract costs
relating to the claim have been incurred and evidence provides a legal basis for the claim. As of
June 30, 2005, the total amount of contract claims filed by the Company with various public
entities was $18,835,979. Of that sum, the Companys portion was $10,548,878 and the balance of
$8,287,101 pertains to a prime contractor or subcontractors claims.
Total claim amounts reported by the Company in its filings are approximate and are subject to
revision as final documentation, resolution of issues, settlements progress and/or payments are
received. Relative to the aforementioned claims, the Company has recorded $3,521,080 in cumulative
claims receivable as of June 30, 2005 to offset a portion of costs incurred to date on the claims.
9
MEADOW
VALLEY CORPORATION AND SUBSIDIARIES
NOTES TO CONDENSED CONSOLIDATED FINANCIAL STATEMENTS (Continued)
1. Summary of Significant Accounting Policies and Use of Estimates (Continued):
Claims Receivable (Continued):
The Company has not accrued a liability related to the prime contractor or subcontractors
claims as no liability would be deemed payable if their portion of the claims did not receive a
favorable outcome, correspondingly, no receivable has been recorded for overhead and profit
included in their portion of the claims on the Companys behalf.
Although the Company believes that the claims receivable amounts represent a reasonably
conservative posture, any claims proceeds ultimately paid to the Company less than the aggregate
amount recorded on the balance sheet of $3,521,080, will decrease earnings. Conversely, a payment
for those same items in excess of $3,521,080 will result in increased income.
A common and customary practice in construction contracts is the owners withholding of a
portion of the contract in the form of retention. Retention practices vary from contract to
contract, but in general, retention (usually between 5% to 10% of the contract) is withheld from
each progress payment by the owner and then paid upon satisfactory completion of the contract.
Contract proceeds comprising retention are included in the Companys balance sheet in accounts
receivable. The portion of accounts receivable pertaining to retention withheld on the contracts
for which claims have been filed amounts to $880,763 as of June 30, 2005. The degree to which the
Company is successful in prosecuting its claims may also impact the amount of retention paid by the
owner.
The Company believes that all retention amounts currently being held by the owners on the
contracts with outstanding claims will be paid in full in accordance with the contract terms.
Therefore, no allowance has been made to reduce the receivables due from the retention on the
disputed contracts.
Stock Option Expense:
In November 1994, the Company adopted a Stock Option Plan providing for the granting of both
qualified incentive stock options and non-qualified stock options. The Company has reserved
1,200,000 shares of its common stock for issuance under the Plan. Granting of the options is at
the discretion of the Board of Directors and may be awarded to employees and consultants.
Consultants may receive only non-qualified stock options. The maximum term of the stock options
are 10 years and may be exercised as follows: 33.3% after one year of continuous service, 66.6%
after two years of continuous service and 100% after three years of continuous service. The
exercise price of each option is equal to the market price of the Companys common stock on the day
of grant.
All stock options issued have an exercise price not less than the fair market value of the
Companys Common Stock on the date of grant. In accordance with accounting for such options
utilizing the intrinsic value method, there is no related compensation expense recorded in the
Companys financial statements for the six months ended June 30, 2005 and 2004. Had compensation
cost for stock-based compensation been determined based on the fair value of the options at the
grant dates consistent with the method of SFAS 123, the Companys net income and earnings per share
for the six months ended June 30, 2005 and 2004 would have been reduced to the pro forma amounts
presented below:
|
|
|
|
|
|
|
|
|
|
|
Six Months Ended |
|
|
June 30, |
|
|
2005 |
|
2004 |
Net income, as reported |
|
$ |
1,250,179 |
|
|
$ |
475,100 |
|
Add: Stock-based employee compensation
expense included in reported income,
net of related tax effects |
|
|
|
|
|
|
|
|
Deduct: Total stock-based employee
compensation expense determined under
fair value based methods for all awards,
net of related tax effects |
|
|
(27,623 |
) |
|
|
(49,688 |
) |
|
|
|
|
|
|
|
|
|
Pro forma net income |
|
$ |
1,222,556 |
|
|
$ |
425,412 |
|
|
|
|
|
|
|
|
|
|
10
MEADOW
VALLEY CORPORATION AND SUBSIDIARIES
NOTES TO CONDENSED CONSOLIDATED FINANCIAL STATEMENTS (Continued)
1. Summary of Significant Accounting Policies and Use of Estimates (Continued):
Stock Option Expense (Continued):
|
|
|
|
|
|
|
|
|
|
|
Six Months Ended |
|
|
June 30, |
|
|
2005 |
|
2004 |
Basic net income per common share |
|
|
|
|
|
|
|
|
As reported |
|
$ |
0.34 |
|
|
$ |
0.13 |
|
Pro forma |
|
|
0.34 |
|
|
|
0.12 |
|
|
|
|
|
|
|
|
|
|
Diluted net income per common share |
|
|
|
|
|
|
|
|
As reported |
|
$ |
0.31 |
|
|
$ |
0.13 |
|
Pro forma |
|
|
0.31 |
|
|
|
0.11 |
|
The fair value of option grants is estimated as of the date of grant utilizing the
Black-Scholes option-pricing model with the following weighted average assumptions for grants in
2003: expected life of options of 3 years, expected volatility of 82.23%, risk-free interest rates
of 5%, and a 0% dividend yield. The weighted average fair value at date of grant for options
granted during 2003 was approximately $.82.
The fair value of option grants is estimated as of the date of grant utilizing the
Black-Scholes option-pricing model with the following weighted average assumptions for grants in
2001: expected life of options of 5 years, expected volatility of 60.85%, risk-free interest rates
of 8%, and a 0% dividend yield. The weighted average fair value at date of grant for options
granted during 2001 was approximately $.97.
Recent Accounting Pronouncements:
In November 2004, the Financial Accounting Standards Board (FASB) issued Statement of
Financial Accounting Standards No. 151 (SFAS 151), Inventory Costs. SFAS 151 amends the
guidance in APB No. 43, Chapter 4, Inventory Pricing, to clarify the accounting for abnormal
amounts of idle facility expense, freight, handling costs, and waste material (spoilage). SFAS 151
requires that those items be recognized as current period charges regardless of whether they meet
the criteria of so abnormal. In addition, SFAS 151 requires that allocation of fixed production
overheads to the costs of conversion be based on the normal capacity of the production facilities.
SFAS 151 is effective for financial statements issued for fiscal years beginning after June 15,
2005. The adoption of SFAS 151 is not expected to have a material effect on the Companys
financial position or results of operations.
In December 2004, FASB issued Statement of Financial Accounting Standards No. 153 (SFAS
153), Exchanges of Nonmonetary Assets. SFAS 153 amends the guidance in APB No. 29, Accounting
for Nonmonetary Assets. APB No. 29 was based on the principle that exchanges of nonmonetary
assets should be measured on the fair value of the assets exchanged. SFAS 153 amends APB No. 29 to
eliminate the exception for nonmonetary exchanges of similar productive assets and replaces it with
a general exception for exchanges of nonmonetary assets that do not have commercial substance in
the future cash flows of the entity are expected to change significantly as a result of the
exchange. SFAS 153 is effective for financial statements issued for fiscal years beginning after
June 15, 2005. The adoption of SFAS 153 is not expected to have a material affect on the Companys
financial position or results of operations.
11
MEADOW
VALLEY CORPORATION AND SUBSIDIARIES
NOTES TO CONDENSED CONSOLIDATED FINANCIAL STATEMENTS (Continued)
1. Summary of Significant Accounting Policies and Use of Estimates (Continued):
Recent Accounting Pronouncements (Continued):
On June 1, 2005, the FASB issued Statement of Financial Accounting Standards No. 154, (SFAS
154), Accounting Changes and Error Corrections, a replacement of APB Opinion No. 20, Accounting
Changes and FASB Statement No. 3, Reporting Accounting Changes in Interim Financial Statements.
SFAS 154 applies to all voluntary changes in accounting principal and changes the requirements for
accounting for and reporting a change in accounting principal. SFAS 154 requires the retrospective
application to prior periods financial statements of the direct effect of a voluntary change in
accounting principle unless it is impracticable. APB No. 20 required that most voluntary changes
in accounting principle be recognized by including in net income of the period of the change the
cumulative effect of changing to the new accounting principle. FASB stated that SFAS 154 improves
financial reporting because its requirements enhance the consistency of financial information
between periods. Unless early adoption is elected, SFAS 154 is effective for fiscal years
beginning after December 15, 2005. Early adoption is permitted for fiscal years beginning after
June 1, 2005. SFAS 154 does not change the transition provisions of any existing accounting
pronouncements, including those that are in a transition phase as of the effective date of this
statement. The adoption of SFAS 154 is not expected to have a material affect on the Companys
financial position or results of operations.
2. Notes Payable:
Notes payable consists of the following:
|
|
|
|
|
|
|
|
|
|
|
June 30, |
|
December 31, |
|
|
2005 |
|
2004 |
Balance of notes payable outstanding from year end |
|
$ |
11,843,549 |
|
|
$ |
16,016,204 |
|
|
|
|
|
|
|
|
|
|
Notes payable, 5.90% interest rate with combined monthly
payments of $7,440, due dates ranging from January 31,
2010 to March 11, 2010, collateralized by vehicles |
|
|
360,918 |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Note payable, 6.71% interest rate with monthly payments of
$35,554, due March 10, 2009, collateralized by equipment |
|
|
1,383,392 |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Notes payable, interest rates ranging from 7.11% to 7.25%
with combined monthly payments of $8,237, due dates ranging
from
May 4, 2009 to June 15, 2009, collateralized by equipment |
|
|
387,064 |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
13,974,923 |
|
|
|
16,016,204 |
|
Less: current portion |
|
|
(4,911,702 |
) |
|
|
(5,212,187 |
) |
|
|
|
|
|
|
|
|
|
|
|
$ |
9,063,221 |
|
|
$ |
10,804,017 |
|
|
|
|
|
|
|
|
|
|
Following are maturities of the long-term debt for each of the next five years:
|
|
|
|
|
2006 |
|
$ |
4,911,702 |
|
2007 |
|
|
3,980,449 |
|
2008 |
|
|
2,567,322 |
|
2009 |
|
|
1,660,524 |
|
2010 |
|
|
854,926 |
|
|
|
|
|
|
|
|
$ |
13,974,923 |
|
|
|
|
|
|
12
MEADOW
VALLEY CORPORATION AND SUBSIDIARIES
NOTES TO CONDENSED CONSOLIDATED FINANCIAL STATEMENTS (Continued)
3. Commitments:
During the six months ended June 30, 2005, the Company leased various pieces of equipment and
vehicles with a combined monthly payment of $74,379. Minimum future rental payments under the
non-cancelable operating leases as of June 30, 2005 and for each of the next five years are:
|
|
|
|
|
2006 |
|
$ |
876,569 |
|
2007 |
|
|
796,669 |
|
2008 |
|
|
788,587 |
|
2009 |
|
|
718,114 |
|
2010 |
|
|
433,044 |
|
|
|
|
|
|
|
|
$ |
3,612,983 |
|
|
|
|
|
|
During the six months ended June 30, 2005, the Company entered into three-year employment
agreements with each of two of its key employees that provide for an annual salary and various
other benefits and incentives. As of June 30, 2005 the total commitments, excluding benefits and
incentives, amount to $612,250.
The Company has agreed to indemnify its officers and directors for certain events or
occurrences arising as a result of the officer or director serving in such capacity. The term of
the indemnification period is for the officers or directors lifetime. The maximum potential
amount of future payments the Company could be required to make under these indemnification
agreements is unlimited. However, the Company has a directors and officers liability insurance
policy that enables it to recover a portion of any future amounts paid. As a result of its
insurance policy coverage, the Company believes the estimated fair value of these indemnification
agreements is minimal and has no liabilities recorded for these agreements as of June 30, 2005.
The Company enters into indemnification provisions under its agreements with other companies
in its ordinary course of business, typically with surety companies, business partners,
contractors, customers, landlords, lenders and lessors. Under these provisions the Company
generally indemnifies and holds harmless the indemnified party for losses suffered or incurred by
the indemnified party as a result of the Companys activities or, in some cases, as a result of the
indemnified partys activities under the agreement. The maximum potential amount of future
payments the Company could be required to make under these indemnification provisions is unlimited.
The Company has not incurred material costs to defend lawsuits or settle claims related to these
indemnification agreements. As a result, the Company believes the estimated fair value of these
agreements is minimal. Accordingly, the Company has no liabilities recorded for these agreements
as of June 30, 2005.
4. Statement of Cash Flows:
Non-Cash Investing and Financing Activities:
The Company recognized investing and financing activities that affected assets and liabilites,
but did not result in cash receipts or payments. These non-cash activities are as follows:
During the six months ended June 30, 2005 and 2004, the Company financed the purchase of
equipment and property in the amounts of $781,113 and $3,831,601, respectively.
During the six months ended June 30, 2005, the Company refinanced a note payable in the amount
of $1,489,570.
13
MEADOW
VALLEY CORPORATION AND SUBSIDIARIES
NOTES TO CONDENSED CONSOLIDATED FINANCIAL STATEMENTS (Continued)
5. Litigation and Claim Matters:
The Company is a party to legal proceedings in the ordinary course of its business. With the
exception of those matters detailed below, the Company believes that the nature of these
proceedings (which generally relate to disputes between the Company and its subcontractors,
material suppliers or customers regarding payment for work performed or materials supplied) are
typical for a construction firm of its size and scope, and no other pending proceedings are deemed
to be materially detrimental and some claims may prove beneficial to its financial condition.
The following proceedings represent matters that may be material and have been referred to
legal counsel for further action:
Requests for Equitable Adjustment to Construction Contracts. The Company has made claims
as described below on the following contracts:
|
(1) |
|
Two contracts with the New Mexico State Highway and Transportation Department
The approximate total value of claims on these projects is $12,002,782 of which
$8,336,931 is on behalf of MVCI and the balance of $3,665,851 is on behalf of the prime
contractor or subcontractors. The primary issues are changed conditions, plan errors
and omissions, contract modifications and associated delay costs. In addition, the
projects were not completed within the adjusted contract time because of events giving
rise to the claims. The prosecution of the claims will include the appropriate
extensions of contract time to offset any potential liquidated damages. A trial date
has been set for summer of 2006. |
|
|
(2) |
|
Clark County Public Works, Clark County, Nevada A final ruling on November 1,
2004, by the three-member arbitration panel awarded MVCI approximately $5,540,000 of
which $2,100,000 is due MVCI and the balance of $3,440,000 is due a subcontractor. The
approximate total value of the claims ruled on above was $6,833,197 of which $2,211,947
was on behalf of MVCI and the balance of $4,621,250 was on behalf of a subcontractor.
MVCI has not recognized any additional claim receivable related to this ruling since
Clark County Public Works has filed, on January 28, 2005 with the District Court, a
Notice of and Motion to Vacate Arbitration Award. The Countys motion was heard on May
9, 2005 and was denied by the District Court, but has now been appealed to the Nevada
Supreme Court. In 2004 the three-member arbitration panel made a partial ruling
rejecting a significant portion of the original claim that was primarily asserted by
another subcontractor on the project. MVCI filed with the District Court a Notice of
and Motion to Vacate Arbitration Award on the Shoring Entitlement. The motion was
denied by the District Court and on February 7, 2005, MVCI filed an appeal to the
Supreme Court of the State of Nevada. The primary issues, related to the claim filed
against Clark County Public Works, were changed conditions, constructive changes,
contract modifications and associated delay costs. |
The combined total of all outstanding claims as of June 30, 2005 is $18,835,979. MVCIs
portion of the total claims is $10,548,878 and the balance pertaining to a prime contractor or
subcontractors claims is $8,287,101. Total claim amounts reported by the Company are approximate
and are subject to revision as final documentation progresses and as issues are resolved and/or
payments made. Claim amounts do not include any prejudgment
interest, if applicable. Relative to the aforementioned claims, MVCI has recorded $3,521,080 in
cumulative claims receivable to offset a portion of costs incurred to date on the claims.
MVCI has not accrued a liability related to the prime contractor or subcontractors claims as
no liability would be deemed payable if their portion of the claims did not receive a favorable
final outcome. Correspondingly, no receivable has been recorded for overhead and profit included
in their portion of the claims on MVCIs behalf.
Although the Company believes that the claims receivable amounts represent a reasonably
conservative posture, any claims proceeds ultimately paid to the Company less than the aggregate
amount recorded on the balance sheet of $3,521,080, will decrease earnings. Conversely, a payment
for those same items in excess of $3,521,080 will result in increased income.
14
MEADOW
VALLEY CORPORATION AND SUBSIDIARIES
NOTES TO
CONDENSED CONSOLIDATED FINANCIAL STATEMENTS (Continued)
5. Litigation and Claim Matters (Continued):
The portion of accounts receivable pertaining to retention withheld on the contracts for which
claims have been filed amounts to $880,763. The degree to which the Company is successful in
prosecuting its claims may also impact the amount of retention paid by the owner. The Company
believes that all retention amounts currently being held by the owners on the contracts with
outstanding claims will be paid in full in accordance with the contract terms. Therefore, no
allowance has been made to reduce the receivables due from the retention on the disputed contracts.
Lawsuits Filed Against Meadow Valley Contractors, Inc.
|
(1) |
|
Innovative Construction Systems, Inc. (ICS), District Court, Clark County, NV
ICS was a subcontractor to MVCI on several projects. ICS failed to make payments of
payroll, pension fund contributions and other taxes for which the Internal Revenue
Service garnished any future payments due ICS on MVCI projects. As a result, ICS
failed to supply labor to perform its work and defaulted on its subcontracts. The
Company terminated the ICS subcontracts and performed the work with MVCIs personnel.
ICS alleges it was wrongfully terminated and is asserting numerous claims for damages.
ICS claims against MVCI total approximately $15,000,000. The Company does not believe
ICS claims have merit and intends to vigorously defend against these claims and has
filed counter-claims for approximately $3,200,000 seeking to recover the damages ICS
has caused MVCI through its failure to perform and satisfy its financial obligations.
As such, no liability has been recorded in the accompanying financial statements for
any potential loss arising from this claim. In September 2003, a binding arbitration
agreement was entered into between ICS and MVCI to stay all actions until the Clark
County, Nevada claim, as mentioned above, has concluded, a decision rendered, payment
received from the county, and the funds are escrowed. As a result of the decisions
referenced above, binding arbitration has been scheduled for February and April of
2006. At that time, all remaining matters between MVCI and ICS will be heard before a
three-person binding arbitration panel. |
|
|
(2) |
|
Johnson & Danley Construction Co., Inc. (JDCC), J.D. Materials, Inc. (JDM)
and Joel T. Danley (Danley) (collectively J&D), Twelfth Judicial District, District
of New Mexico JDCC was the prime contractor and MVCI was a subcontractor to JDCC on
one of the two contracts involved in MVCIs disputes with the state of New Mexico.
JDCC was also a subcontractor to MVCI on other contracts in New Mexico. JDM is the
owner of an aggregate pit in Alamogordo, NM and leased the pit to MVCI under a mineral
lease agreement. Danley is believed to be an officer and owner of JDCC and JDM. JDCC
filed for Chapter 11 bankruptcy protection, which in accordance with the contract,
resulted in the termination of its contract with the New Mexico State Highway and
Transportation Department (NMSHTD). The payment and performance bonds supplied by
JDCC in connection with the one contract for which JDCC was the prime contractor had
been furnished by the Companys surety companies. MVCI indemnified the surety
companies against losses and claims on the one contract. Upon JDCCs termination, the
NMSHTD entered into a takeover agreement with the surety companies who subsequently
entered into an agreement with MVCI to complete the work. MVCI has successfully
completed the projects. In its complaint, J&D alleged, among other things, that MVCI
was partially responsible for the cause of its bankruptcy and sought damages in an
undetermined amount. On February 10, 2003 for mutual consideration, J&D and MVCI
entered into a settlement
agreement whereby the two parties dismissed their claims and counterclaims in their
entirety. The parties have agreed to jointly prosecute their respective claims against
the NMSHTD. |
|
|
(3) |
|
MVCI is defending a claimed preference, in the Third Judicial Court of Salt
Lake County, in connection with a payment made to it by an insurance company, Southern
America Insurance Company, in the approximate amount of $100,000. MVCI believes that
the payment is not a preference, and is vigorously defending the action. |
15
MEADOW
VALLEY CORPORATION AND SUBSIDIARIES
NOTES TO CONDENSED CONSOLIDATED FINANCIAL STATEMENTS (Continued)
5. Litigation and Claim Matters (Continued):
|
(4) |
|
MVCI has been named in two civil actions filed in Nevada District Court, Clark
County, Nevada as a result of a fatal traffic accident involving one of its trucks. The
first complaint, Case No. A485620, was filed on April 14, 2004 and is a civil action
titled Shotzie Thomas, individually and as Administratrix of the Estate of Emberly
Thomas, vs. Duward Leslie Vernon, Meadow Valley Contractors, Inc. d/b/a Meadow Valley
Contractors, Lawrence M. Thomas and Does I-X and Roes I-X. The second complaint, Case
No. A490720, was filed August 19, 2004 and is a civil action titled Arthur M. Hoolmalu,
individually and as Special Administrator of the Estate of Tulare M. Adams, deceased,
and Sandra K. Adams and Michael Adams, dependent parents, vs. Duward Leslie Vernon,
Meadow Valley Contractors, Inc. d/b/a Meadow Valley Contractors, Lawrence M. Thomas,
American Family Insurance Company and Does I-X and Roes I-X. The complaint seeks
damages from MVCI for losses suffered by the plaintiffs as a result of the accident.
In March 2005, the estate of Emberly Thomas settled for an undisclosed amount which was
paid by the Companys insurance company. The Company intends to vigorously defend this
remaining action. Since the remaining complaint seeks an amount to be determined, the
Company can not estimate the range of a potential loss. There can be no assurance that
a judgment, if any, against us will be within our insurance coverage. |
6. Earnings per Share:
The Companys basic net income per share for the six months ended June 30, 2005 and 2004 were
computed by dividing net income for the period by 3,629,028 and 3,601,250, respectively, the basic
weighted average number of common shares outstanding during the period.
The Companys diluted net income per common share for the six months ended June 30, 2005 was
computed based on the weighted average number of shares of common stock outstanding during the
period and the weighted average of options to purchase 776,214 shares at a range of $1.46 to $5.41.
Options to purchase 191,025 shares at a range of $5.875 to $6.25 per share were outstanding during
2005, but were not included in the computation of diluted net income per common shares because the
options exercise price was greater than the average market price of the common share.
The Companys diluted net income per common share for the six months ended June 30, 2004 was
computed based on the weighted average number of shares of common stock outstanding during the
period and the weighted average of options to purchase 369,000 shares at a price of $1.46. Options
to purchase 699,875 shares at a range of $2.44 to $6.25 per share were outstanding during 2004, but
were not included in the computation of diluted net income per common shares because the options
exercise price was greater than the average market price of the common share.
7. Subsequent Events:
During July 2005, the Company was the successful bidder on contracts valued at approximately
$5.5 million that should be awarded during August 2005 at which time the contract value will be
added to backlog.
During July 2005, the Company purchased rights to a material purchase contract and mining
water rights in the northwest Las Vegas area in the amount of $2,250,000 and financed $1,800,000
with a note payable obligation. The note payable obligation has an interest rate of prime plus one and one-half percent with a
monthly principal payment of $21,429 plus interest and is due July 29, 2012.
During July 2005, the Company leased a piece of equipment, with a monthly payment of $12,800
for seven lease payments, after which the periodic payment is reduced to $5,390. The operating
lease expires in June 2008.
16
MEADOW
VALLEY CORPORATION AND SUBSIDIARIES
NOTES TO CONDENSED CONSOLIDATED FINANCIAL STATEMENTS (Continued)
8. Segment Information:
The Company manages and operates two segments construction services and construction
materials. The construction services segment provides construction services to a broad range of
public and some private customers primarily in the western states of Arizona, Nevada and Utah.
Through this segment, the Company performs heavy civil construction such as the construction of
bridges and overpasses, channels, roadways, highways and airport runways. The construction
materials segment manufactures and distributes ready-mix concrete and sand and gravel products in
the Las Vegas, NV and Phoenix, AZ markets. Material customers include concrete subcontractors,
prime contractors, homebuilders, commercial and industrial property developers, pool builders and
homeowners. The construction materials segment operates out of two locations in the Las Vegas, NV
vicinity, one location in the Moapa, NV vicinity and two locations in the Phoenix, AZ vicinity.
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Six Months Ended June 30, |
(dollars in thousands) |
|
2005 |
|
2004 |
|
|
Construction |
|
Construction |
|
|
Services |
|
Materials |
|
Services |
|
Materials |
Gross revenue |
|
$ |
62,059 |
|
|
$ |
31,817 |
|
|
$ |
54,436 |
|
|
$ |
28,451 |
|
Intercompany revenue |
|
|
|
|
|
|
(507 |
) |
|
|
|
|
|
|
(10 |
) |
Cost of revenue |
|
|
59,625 |
|
|
|
28,666 |
|
|
|
53,223 |
|
|
|
25,597 |
|
Interest income |
|
|
277 |
|
|
|
14 |
|
|
|
22 |
|
|
|
24 |
|
Interest expense |
|
|
(107 |
) |
|
|
(131 |
) |
|
|
(100 |
) |
|
|
(95 |
) |
Intercompany interest income (expense) |
|
|
54 |
|
|
|
(54 |
) |
|
|
|
|
|
|
|
|
Depreciation and amortization |
|
|
1,002 |
|
|
|
1,151 |
|
|
|
748 |
|
|
|
673 |
|
Income (loss) before taxes |
|
|
488 |
|
|
|
1,465 |
|
|
|
(797 |
) |
|
|
1,555 |
|
Income tax benefit (expense) |
|
|
(176 |
) |
|
|
(527 |
) |
|
|
300 |
|
|
|
(583 |
) |
Net income (loss) |
|
|
313 |
|
|
|
937 |
|
|
|
(497 |
) |
|
|
972 |
|
Total assets |
|
|
42,639 |
|
|
|
22,611 |
|
|
|
36,277 |
|
|
|
18,934 |
|
There are no differences in accounting principals between the segments. All centrally
incurred costs are allocated to the construction services segment. Beginning in 2005, a management
fee is allocated to the materials segment in the amount of $22,000 per month. Inter-company
revenue is eliminated at cost to arrive at consolidated revenue and cost of revenue.
17
Item 2. Managements Discussion and Analysis of Financial Condition and Results of Operations
Forward-Looking Disclosure
This Quarterly Report on Form 10-Q contains forward-looking statements within the meaning of
the safe harbor provision of the Private Securities Litigation Reform Act of 1995 regarding
future events and the future results of Meadow Valley Corporation that are based on current
expectations, estimates, forecasts, and projections as well as the beliefs and assumptions of
Meadow Valleys management. Words such as outlook, believes, expects, appears, may,
will, should, anticipates or the negative thereof or comparable terminology, are intended to
identify such forward-looking statements. These forward-looking statements are only predictions
and are subject to risks, uncertainties and assumptions that are difficult to predict. Therefore
actual results may differ materially and adversely from those expressed in any forward-looking
statements. Factors that might cause or contribute to such differences include, but are not
limited to those discussed in our Annual Report on Form 10-K under the section entitled
Quantitative and Qualitative Disclosures about Market Risk. You should not place undue reliance
on these forward-looking statements, which speak only as of the date of this Quarterly Report.
Meadow Valley Corporation undertakes no obligation to revise or update publicly any forward-looking
statements for any reason.
General
The following is managements discussion and analysis of certain significant factors affecting
the Companys financial position and operating results during the periods included in the
accompanying condensed consolidated financial statements.
Except for the historical information contained herein, the matters set forth in this report
are forward-looking statements.
Revenue on uncompleted fixed price contracts is recorded under the percentage-of-completion
method of accounting. We begin to recognize revenue on our contracts when we first incur direct
costs. Contracts often involve work periods in excess of one year and revisions in cost and profit
estimates during construction are reflected in the accounting period in which the facts that
require the revisions become known. Losses on contracts, if any, are provided for in total when
determined, regardless of the percent complete.
In general, labor, equipment and disposable materials tend to be the types of costs with the
greatest uncertainty, and, therefore, have the greatest risk of variation from budgeted costs.
Permanent materials and subcontract costs tend to be more predictable and, to a greater degree, can
be fixed for the duration of the contract, thus have less risk of variation from the original
estimate. In recent months, however, nearly the entire United States construction industry has
been impacted by materials shortages and rising costs of key commodities such as steel, cement and
petroleum-based products. To date we have managed to avoid material deterioration of profit
margins due to untimely delivery of important construction materials or from rapidly rising costs
of the same, but have not escaped constrained revenue from the construction materials segment
caused by cement powder allocations or from minor cost overruns due to rising costs of raw
materials in our construction services segment. A significant and unforeseen rise in the cost of
crude oil could negatively impact our performance. Likewise, prolonged shortages of raw materials
could delay progress on projects, cause cost overruns and potentially erode profit margins.
Overview
The second quarter experienced a significant rebound from the weather-impacted first quarter.
Both revenue and profit improved substantially from last quarter and from the same period in the
prior fiscal year. Much of the improvement stems from not having any significant weather impacts during the quarter,
but also from a carry-forward of work into the second quarter that had previously been delayed.
Our operating results also benefited from having achieved improvements in both of our
segments, each of which experienced increased revenue and increased profits. It is also noteworthy
that in August 2005 we achieved substantial completion of the troublesome Gooseberry project in
central Utah. We expect to finish minor punch-list items and leave the project entirely in August.
Although the physical work will be completed, there are a number of contractual items that will
still need to be resolved with the owner. We continue to believe that we have adequately reserved
for losses on this project and that it will not have any negative impact on any future periods.
The construction materials segment continues to benefit from strong demand in its markets even
while coping with
18
occasional scarcity of cement. We remain on schedule with the construction of
the third materials production facility in the southwest Las Vegas area which we anticipate will
begin production in the third quarter of 2005 and have also successfully acquired a location for a
future facility in the northwest Las Vegas area.
Construction services contract backlog (anticipated revenue from the uncompleted portions of
awarded projects) was approximately $62.5 million at June 30, 2005, compared to approximately $67.5
million at June 30, 2004. At June 30, 2005, our backlog includes approximately $50.0 million of
work that is scheduled for completion during 2005.
Critical Accounting Policies, Estimates and Judgments
Significant accounting policies are described in the audited consolidated financial statements
and notes thereto included in the Companys Annual Report on Form 10-K for the year ended December
31, 2004. We believe our most critical accounting policies are the revenue recognition and cost
estimation on certain contracts for which we use a percentage-of-completion accounting method, our
allowance for doubtful accounts and the inventory allowance. The revenue recognition and cost
estimation accounting method is applied by our construction services segment to heavy construction
projects executed under multi-year contracts with various customers.
Revenues and costs from fixed-price and modified fixed-price construction contracts are
recognized for each contract on the percentage-of-completion method, measured by the percentage of
costs incurred to date to the estimated total of direct costs. Direct costs include, among other
things, direct labor, field labor, equipment rent, subcontracting, direct materials, and direct
overhead. General and administrative expenses are accounted for as period costs and are,
therefore, not included in the calculation of the estimates to complete construction contracts in
progress. Project losses are provided in the period in which such losses are determined, without
reference to the percentage-of-completion. As contracts can extend over one or more accounting
periods, revisions in costs and earnings estimated during the course of the work are reflected
during the accounting period in which the facts that required such revisions become known.
The asset costs and estimated earnings in excess of billings on uncompleted contracts
represents revenue recognized in excess of amounts billed. The liability billings in excess of
costs and estimated earnings on uncompleted contracts represents billings in excess of revenues
recognized.
The complexity of the estimation process and all issues related to the assumptions, risks and
uncertainties inherent with the application of the percentage-of-completion method of accounting
affects the amounts reported in our financial statements. A number of internal and external
factors affect our percentage-of-completion estimates, including labor rates and efficiency
variances, estimated future material prices and customer specification changes. If our business
conditions were different, or if we used different assumptions in the application of this
accounting policy, it is likely that materially different amounts would be reported in our
financial statements.
We are also required to estimate the collectibility of our accounts receivable. A
considerable amount of judgment is required in assessing the realization of these receivables,
including the current credit worthiness of each customer and the related aging of the past due
balances. Our provision for bad debts at June 30, 2005 and December 31, 2004 amounted to $709,591
and $607,677, respectively. We determine our reserve by using percentages applied to certain aged
receivable categories and percentages of certain types of revenue generated, as well as a review of
the individual accounts outstanding.
In addition, we are required to state our inventories at the lower of cost or market. In
assessing the ultimate realization of inventories, we are required to make judgments as to the
future demand requirements and compare these with the current inventory levels. Our reserve
requirements generally increase as our projected demand
requirements decrease due to market conditions and longer than expected usage periods. At
June 30, 2005 and December 31, 2004, inventories of $961,147 and $871,112, are each net of reserves
of $286,822. It is possible that significant changes in required inventory reserves may occur in
the future if there are changes in market conditions.
As discussed elsewhere in this filing, we disclose various litigation and claims matters.
These issues involve significant estimates and judgments, which may materially change in future
periods due to change in circumstances.
19
Results of Operations
The following table sets forth, for the six months and three months ended June 30, 2005 and
2004, certain items derived from the Companys Condensed Consolidated Statements of Operations
expressed as a percentage of revenue.
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Six Months Ended |
|
Three Months Ended |
|
|
June 30, |
|
June 30, |
|
|
2005 |
|
2004 |
|
2005 |
|
2004 |
Revenue |
|
|
100.0 |
% |
|
|
100.0 |
% |
|
|
100.0 |
% |
|
|
100.0 |
% |
Gross profit |
|
|
6.0 |
% |
|
|
4.9 |
% |
|
|
6.8 |
% |
|
|
3.7 |
% |
General and administrative expenses |
|
|
4.1 |
% |
|
|
3.7 |
% |
|
|
4.0 |
% |
|
|
3.3 |
% |
Interest income |
|
|
0.3 |
% |
|
|
0.0 |
% |
|
|
0.1 |
% |
|
|
0.1 |
% |
Interest expense |
|
|
-0.2 |
% |
|
|
-0.2 |
% |
|
|
-0.2 |
% |
|
|
-0.3 |
% |
Income before income taxes |
|
|
2.1 |
% |
|
|
0.9 |
% |
|
|
2.9 |
% |
|
|
0.1 |
% |
Income tax expense |
|
|
-0.8 |
% |
|
|
-0.3 |
% |
|
|
-1.0 |
% |
|
|
0.0 |
% |
Net income |
|
|
1.3 |
% |
|
|
0.6 |
% |
|
|
1.9 |
% |
|
|
0.1 |
% |
Six Months Ended June 30, 2005 Compared to Six Months Ended June 30, 2004
Revenue and Backlog. Consolidated revenue for the six months ended June 30, 2005 (interim
2005) was $93.4 million compared to $82.9 million for the six months ended June 30, 2004 (interim
2004). The increase in revenue was the result of a $7.6 million increase in revenue from the
construction services segment, complemented by a $2.9 million increase in revenue from the
construction materials segment. The increase in the construction services segment revenue was the
result of the progress schedules and the nature of the contracts contained in the backlog at the
beginning of interim 2005 and impacted less by the amount of the beginning backlog. The increase
in the construction materials segment was a result of an average unit sales price increase of 18.8%
in interim 2005 from interim 2004; while the volume, sale of cubic yards of concrete, which we
referred to as units, decreased approximately 6.0% in interim 2005 from interim 2004. The
increased average unit sales price reflects our ability to pass on additional costs to our
customers, such as the increased costs of raw materials and transportation of those materials. The
decreased volume in the six months ended June 30, 2005 was primarily due to wet weather conditions
during January and February.
Gross Profit. Consolidated gross profit increased to $5.6 million for interim 2005 from $4.1
million for interim 2004 and consolidated gross margin, as a percent of revenue, increased to 6.0%
in interim 2005 from 4.9% in interim 2004. Gross profit from construction materials increased to
$3.2 million in interim 2005 from $2.9 million in interim 2004 and the gross profit margin
increased to 10.1% from 10.0% in the respective periods. The increase in the gross profit margin
in the construction materials segment during interim 2005 was the result of an increase in the
average unit sales price, reduced slightly by a lower volume of unit sales when compared to interim
2004. Gross profit from construction services increased to $2.4 million in interim 2005 compared
to $1.2 million in interim 2004 and the gross profit margin increased to 3.9% from 2.2% in the
respective periods. The increase in the gross profit margin during the interim 2005 when compared
to interim 2004 was primarily the result of having no additional losses to recognize on the
Gooseberry project, whereas in interim 2004 we had recognized additional losses of approximately
$1.2 million during interim 2004. Gross profit margins are affected by a variety of factors
including the quality and accuracy of the original estimate, construction delays and difficulties
due to weather conditions, availability of materials, the timing of work performed by other
subcontractors and the physical and
geological condition of the construction site, therefore the gross profit in interim 2005 may not
be indicative of the annual gross profit margin.
General and Administrative Expenses. General and administrative expenses increased to $3.8
million for interim 2005 from $3.1 million for interim 2004. The increase in the general and
administrative expenses was the result of an increase of $.5 million in employee compensation
expense, an increase of $.1 million in legal expense, an increase $.1 million in public company
reporting and accounting expenses and an increase of $.1 million in our marketing and customer
relations expense, offset by a decrease of $.1 million in bad debt expense.
20
Interest Income and Expense. Interest income for interim 2005 increased to $.24 million from
$.05 million for interim 2004 resulting from a court order placed upon a subcontractor to pay
interest, in addition to reimbursing us for costs incurred to complete their obligations and legal
fees. Interest expense for interim 2005 decreased to $.18 million compared to $.2 million for
interim 2004, due primarily to the repayment of our non-equipment related debt. Interest expense
directly related to equipment is expensed as a cost of the equipment and is included in the cost of
revenue. The increase in other income (expense) was a result of the above mentioned court order
placed upon a subcontract to reimburse us for legal fees associated with the collection of costs to
complete their obligations.
Income Taxes. The increase in the income tax provision for interim 2005 to $.7 million
compared to an income tax provision of $.3 million for interim 2004 was due to an increase in the
pre-tax income during interim 2005. The difference between the amount of the tax provision and the
actual cash outlay is due to the net operating loss carry-forward.
Net Income. Net income was $1.25 million in interim 2005 as compared to a net income of $.48
million for interim 2004.
Three Months Ended June 30, 2005 Compared to Three Months Ended June 30, 2004
Revenue and Backlog. Consolidated revenue for the three months ended June 30, 2005 (2nd
quarter 2005) was $53.4 million compared to $43.7 million for the three months ended June 30, 2004
(2nd quarter 2004). The increase in revenue was the result of a $7.3 million increase in revenue
from the construction services segment, complemented by a $2.5 million increase in revenue from the
construction materials segment. The increase in the construction services segment revenue was the
result of the progress schedules and the nature of the contracts contained in the backlog at the
beginning of interim 2005 and impacted less by the amount of the beginning backlog. The increase
in the construction materials segment was due primarily to an increase of 19.3% in the average unit
sales price, offset by a decrease of 1.5% in the volume of units sold in 2nd quarter 2005 from 2nd
quarter 2004.
Gross Profit. Consolidated gross profit increased to $3.6 million for 2nd quarter 2005 from
$1.6 million for 2nd quarter 2004 and consolidated gross margin, as a percent of revenue, increased
to 6.8% in 2nd quarter 2005 from 3.7% in 2nd quarter 2004. Gross profit from construction services
increased to $1.6 million in 2nd quarter 2005 compared to $.1 million in 2nd quarter 2004 and the
gross profit margin increased to 4.3% from .3% in the respective periods. The increase in the
gross profit margin during the 2nd quarter 2005 when compared to 2nd quarter 2004 was contributed
to having no additional losses to recognize on the Gooseberry project, whereas in 2nd quarter 2004
we had recognized additional losses of approximately $1.2 million during the 2nd quarter 2004.
Gross profit margins are affected by a variety of factors including quality and accuracy of the
original estimate, construction delays and difficulties due to weather conditions, availability of
materials, the timing of work performed by other subcontractors and the physical and geological
condition of the construction site, therefore the gross profit in 2nd quarter 2005 may not be
indicative of the annual gross profit margin. Gross profit from construction materials increased
to $2.1 million in 2nd quarter 2005 from $1.5 million in 2nd quarter 2004 and the gross profit
margin increased to 11.9% from 10.1% in the respective periods. The increase in the gross profit
margin in the construction materials segment during 2nd quarter 2005 is the result of the increase
in the average unit sales price, while disbursement of our fixed costs, which were consistent with
the prior period, over a similar volume of unit sales when compared to 2nd quarter 2004.
General and Administrative Expenses. General and administrative expenses increased to $2.2
million for 2nd quarter 2005 from $1.4 million for 2nd quarter 2004. The increase in the general
and administrative expenses was the result of an increase of $.6 million in employee compensation
expense, an increase of $.1 million in legal expense and an increase of $.1 million in public
company reporting and accounting expenses.
Interest Income and Expense. Interest income for 2nd quarter 2005 increased to $.05 million
from $.03 million for 2nd quarter 2004 resulting primarily from an increase in invested cash
reserves. Interest expense for 2nd quarter 2005 decreased to $.09 million from $.11 million for
2nd quarter 2004 as a result of the reduction of our non-equipment related debt. Interest expense
directly related to equipment is expensed as a cost of the equipment and is included in the cost of
revenue.
21
Income Taxes. The increase in the income tax provision for 2nd quarter 2005 to $.6 million
compared to an income tax provision of less than $.1 million for 2nd quarter 2004 was due to an
increase in the pre-tax income during 2nd quarter 2005. The difference between the amount of the
tax provision and the actual cash outlay is due to the net operating loss carry-forward.
Net Income. Net income was $1.00 million in 2nd quarter 2005 as compared to a net income of
$.04 million for 2nd quarter 2004.
Liquidity and Capital Resources
Our primary need for capital continues to be the expansion of our construction materials
segment. As we expand our business we will continue to utilize the availability of capital offered
by financial institutions, in turn increasing our total debt and debt service obligations.
We are continuing our investigation into alternative sites in the Southwest Phoenix
metropolitan area to eventually locate a third ready-mix facility. Construction of a ready-mix
production facility, as part of our expansion plan in the southwest Las Vegas metropolitan area, is
currently on schedule and is anticipated to begin operations in the third quarter 2005. We have
also successfully acquired a location for a future raw material and production facility in the
northwest Las Vegas area.
Historically, our primary source of cash has been from operations and various financial
institutions. We believe our historical sources of capital will be satisfactory to meet our needs
for the coming twelve months.
The following table sets forth for the six months ended June 30, 2005 and 2004, certain items
from the condensed consolidated statements of cash flows.
|
|
|
|
|
|
|
|
|
|
|
Six Months Ended |
|
|
June 30, |
|
|
2005 |
|
2004 |
Cash flows
provided by (used in) operating activities |
|
$ |
(152,473 |
) |
|
$ |
4,585,842 |
|
Cash flows used in investing activities |
|
|
(1,767,687 |
) |
|
|
(1,263,841 |
) |
Cash flows used in financing activities |
|
|
(2,946,401 |
) |
|
|
(2,375,131 |
) |
Cash used in operating activities during interim 2005 of $.2 million represents a $4.8 million
decrease from the amount provided by operating activities during interim 2004. The change was
primarily due to the increase in our accounts receivable, as a result of our increased revenue
during interim 2005, in the amount of $4.9 million compared to an increase of $1.0 million during
interim 2004 and the reduction of the claim receivable collected during interim 2004 in the amount
of $4.1 million, offset by an increase in the cash inflow as it relates to our contracts in
progress in the amount of $1.4 million when compared to an increase of $.5 million during interim
2004, a depreciation and amortization of $2.2 million compared to $1.4 million during interim 2004
and improved net income of $1.3 million compared to $.5 million during interim 2004.
Cash used in investing activities during interim 2005 of $1.8 million represents a $.6 million
increase from the amount used in investing activates during interim 2004. Investing activities
during interim 2005 was due primarily to capital expenditures of $1.7 million and an increase of
$.3 million in restricted cash, offset by cash received from the disposal of assets of $.2 million.
Investing activities during interim 2004 included cash expended
for capital expenditures of $1.9 million, offset by cash received from the sale of property
and equipment of $.5 million and a reduction of $.1 million in restricted cash.
Cash used in financing activities during interim 2005 of $2.9 million represents a $.5 million
increase from the amount used in financing activities during interim 2004. Financing activities
during interim 2005 included the repayment of notes payable and capital lease obligations of $3.1
million, offset by the cash received from the issuance of common stock on exercised options of $.2
million. Financing activities during interim 2004 included the repayment of notes payable and
capital lease obligations of $2.6 million, offset by the receipt of $.2 million in loan proceeds.
22
Recent Accounting Pronouncements
In November 2004, the Financial Accounting Standards Board (FASB) issued Statement of
Financial Accounting Standards No. 151 (SFAS 151), Inventory Costs. SFAS 151 amends the
guidance in APB No. 43, Chapter 4, Inventory Pricing, to clarify the accounting for abnormal
amounts of idle facility expense, freight, handling costs, and waste material (spoilage). SFAS 151
requires that those items be recognized as current period charges regardless of whether they meet
the criteria of so abnormal. In addition, SFAS 151 requires that allocation of fixed production
overheads to the costs of conversion be based on the normal capacity of the production facilities.
SFAS 151 is effective for financial statements issued for fiscal years beginning after June 15,
2005. The adoption of SFAS 151 is not expected to have a material effect on our financial position
or results of operations.
In December 2004, FASB issued Statement of Financial Accounting Standards No. 153 (SFAS
153), Exchanges of Nonmonetary Assets. SFAS 153 amends the guidance in APB No. 29, Accounting
for Nonmonetary Assets. APB No. 29 was based on the principle that exchanges of nonmonetary
assets should be measured on the fair value of the assets exchanged. SFAS 153 amends APB No. 29 to
eliminate the exception for nonmonetary exchanges of similar productive assets and replaces it with
a general exception for exchanges of nonmonetary assets that do not have commercial substance in
the future cash flows of the entity are expected to change significantly as a result of the
exchange. SFAS 153 is effective for financial statements issued for fiscal years beginning after
June 15, 2005. The adoption of SFAS 153 is not expected to have a material affect on our financial
position or results of operations.
On June 1, 2005, the FASB issued Statement of Financial Accounting Standards No. 154, (SFAS
154), Accounting Changes and Error Corrections, a replacement of APB Opinion No. 20, Accounting
Changes and FASB Statement No. 3, Reporting Accounting Changes in Interim Financial Statements.
SFAS 154 applies to all voluntary changes in accounting principal and changes the requirements for
accounting for and reporting a change in accounting principal. SFAS 154 requires the retrospective
application to prior periods financial statements of the direct effect of a voluntary change in
accounting principle unless it is impracticable. APB No. 20 required that most voluntary changes
in accounting principle be recognized by including in net income of the period of the change the
cumulative effect of changing to the new accounting principle. FASB stated that SFAS 154 improves
financial reporting because its requirements enhance the consistency of financial information
between periods. Unless early adoption is elected, SFAS 154 is effective for fiscal years
beginning after December 15, 2005. Early adoption is permitted for fiscal years beginning after
June 1, 2005. SFAS 154 does not change the transition provisions of any existing accounting
pronouncements, including those that are in a transition phase as of the effective date of this
statement. The adoption of SFAS 154 is not expected to have a material affect on our financial
position or results of operations.
Website Access
Our
website address is www.meadowvalley.com. On our website we make available, free of
charge, our annual report on Form 10-K, our most recent quarterly reports on Form 10-Q, current
reports on Form 8-K, Forms 3, 4, and 5 related to Beneficial Ownership of Securities, and all
amendments to those reports as soon as reasonably practicable after such material is electronically
filed with or furnished to the United States Securities and Exchange Commission. In addition, we
have a copy of our code of ethics. The information on our website is not incorporated into, and is
not part of, this report.
Item 3. Quantitative and Qualitative Disclosure About Market Risk
Reference is made to Meadow Valley Corporations most recently issued Annual Report and in
particular the Quantitative and Qualitative Disclosures about Market Risk included in
Managements Discussion and Analysis of Financial Condition and Results of Operations. As of June
30, 2005, there have been no material changes in the market risks described in Meadow Valley
Corporations most recently issued Annual Report.
23
Item 4. Controls and Procedures
As of the end of the period covered by this Quarterly Report on Form 10-Q, the Corporation
carried out an evaluation, under the supervision and with the participation of the Corporations
management, including the Chief Executive Officer and the Principal Accounting Officer, of the
effectiveness of the design and operation of the Corporations disclosure controls and procedures
pursuant to Exchange Act Rule 13a-15(e). Based upon that evaluation, the Chief Executive Officer
and the Principal Accounting Officer concluded that the Corporations disclosure controls and
procedures are effective in timely alerting them to material information relating to the
Corporation (including its consolidated subsidiaries) required to be included in the Corporations
periodic SEC filings. During the quarter, there have been no significant changes in the
Corporations internal control over financial reporting or in other factors that could
significantly affect internal control over financial reporting.
PART
II OTHER INFORMATION
Item 1. Legal Proceedings
For information about litigation involving us, see note 5 to the condensed consolidated
financial statements in Part I of this report, which we incorporate by reference into this Item 1.
Item 2. Unregistered Sales of Equity Securities and Use of Proceeds
None
Item 3. Defaults Upon Senior Securities
None
Item 4. Submission of Matters to a Vote of Security Holders
At the Companys Annual Meeting of Shareholders on June 14, 2005, nominees for Class B
Directors as listed in the proxy statement, to hold office for a three year term, expiring 2008 or
until election and qualification of their successors or until their resignation, death,
disqualification or removal from office were elected by the holders of Common Stock with the
following vote:
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Affirmative |
|
Negative |
|
Authority |
Class B Directors |
|
Votes |
|
Votes |
|
Withheld |
Gary A. Agron |
|
|
2,902,633 |
|
|
|
|
|
|
|
137,949 |
|
Earle C. May |
|
|
2,916,418 |
|
|
|
|
|
|
|
124,164 |
|
Proposal to ratify the selection of Semple and Cooper, LLP as the independent registered
public accounting firm for the fiscal year ending December 31, 2005 was approved by the holders of
Common Stock with the following vote:
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Affirmative |
|
Negative |
|
Authority |
|
|
Votes |
|
Votes |
|
Withheld |
|
|
|
3,037,982 |
|
|
|
600 |
|
|
|
2,000 |
|
Proposal to approve the Companys 2004 Equity Incentive Plan was approved by the holders of
Common Stock with the following vote:
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Affirmative |
|
Negative |
|
Authority |
|
|
Votes |
|
Votes |
|
Withheld |
|
|
|
872,137 |
|
|
|
520,391 |
|
|
|
2,000 |
|
24
Item 5. Other Information
None
Item 6. Exhibits
Exhibits:
|
31.1 |
|
Certification of Chief Executive Officer pursuant to Section 302 of the
Sarbanes-Oxley Act of 2002. |
|
|
31.2 |
|
Certification of Principal Accounting Officer pursuant to Section 302 of the
Sarbanes-Oxley Act of 2002. |
|
|
32.1 |
|
Certifications of Chief Executive Officer and Principal Accounting Officer
pursuant to 18 U.S.C. Section 1350, as adopted pursuant to Section 906 of the
Sarbanes-Oxley Act of 2002. |
SIGNATURE
Pursuant to the requirements of the Securities and Exchange Act as of 1934, the Registrant has duly
caused this report to be signed on its behalf by the undersigned thereunto duly authorized.
|
|
|
|
|
|
|
|
|
MEADOW VALLEY CORPORATION |
|
|
|
|
(Registrant) |
|
|
|
|
|
|
|
By
|
|
/s/ Bradley E. Larson |
|
|
|
|
|
|
|
|
|
Bradley E. Larson |
|
|
|
|
President and Chief Executive Officer |
|
|
|
|
|
|
|
By
|
|
/s/ Clint Tryon |
|
|
|
|
|
|
|
|
|
Clint Tryon |
|
|
|
|
Principal Accounting Officer, Secretary and Treasurer |
25