Table of Contents
UNITED STATES SECURITIES AND EXCHANGE COMMISSION
Washington, D.C. 20549
FORM 10-K
| þ | ANNUAL REPORT PURSUANT TO SECTION 13 OR 15 (d) OF THE SECURITIES EXCHANGE ACT OF 1934 |
For the fiscal year ended December 31, 2006
| o | TRANSITION REPORT PURSUANT TO SECTION 13 OR 15 (d) OF THE SECURITIES EXCHANGE ACT OF 1934 |
For the transition period from to
Commission file number 0-25428
MEADOW VALLEY CORPORATION
(Exact name of registrant as specified in its charter)
| Nevada (State or other jurisdiction of incorporation or organization) |
88-0328443 (I.R.S. Employer Identification No.) |
|
| 4602 E. Thomas Road, Phoenix, AZ (Address of principal executive offices) |
85018 (Zip Code) |
Registrant’s telephone number, including area code: (602) 437-5400
Securities registered pursuant to Section 12(b) of the Act: None
Securities registered pursuant to Section 12(g) of the Act:
| Title of each class: | Name of exchange on which registered: | |
| Common stock, $.001 par value | Nasdaq Capital Market |
Indicate by check mark whether the registrant is a well-known seasoned issuer, as defined in Rule
405 of the Securities Act. Yes o No þ
Indicate by check mark whether the registrant is not required to file reports pursuant to Section
13 or Section 15(d) of the Act. Yes o No þ
Indicate by check mark whether the registrant (1) has filed all reports required to be filed by
Section 13 or 15(d) of the Securities Exchange Act of 1934 during the preceding 12 months (or for
such shorter period that the registrant was required to file such reports), and (2) has been
subject to such filing requirements for the past 90 days. Yes
þ No o
Indicate by check mark if disclosure of delinquent filers pursuant to Item 405 of Regulation S-K is
not contained herein, and will not be contained, to the best of registrant’s knowledge, in
definitive proxy or information statements incorporated by reference in Part III of this Form 10-K
or any amendment to this Form 10-K. o
Indicate by check mark whether the registrant is a large accelerated filer, an accelerated filer,
or a non-accelerated filer (as defined in Rule 12b-2 of the Exchange Act).
Large accelerated filer o; Accelerated filer o; Non-accelerated filer þ
Indicate by check mark whether the registrant is a shell company (as defined in Rule 12b-2 of the
Exchange Act). Yes o No þ
On June 30, 2006, the aggregate market value of the registrant’s voting and non-voting common
equity stock held by non-affiliates was $46,016,084.
On March 15, 2007, there were 5,125,760 shares of Common Stock outstanding.
DOCUMENTS INCORPORATED BY REFERENCE
The registrant incorporates by reference into Part III of this Report, information contained in its
definitive proxy statement to be disseminated in connection with its Annual Meeting of Shareholders
for the year ended December 31, 2006.
MEADOW VALLEY CORPORATION
ANNUAL REPORT ON FORM 10-K
FOR THE YEAR ENDED DECEMBER 31, 2006
ANNUAL REPORT ON FORM 10-K
FOR THE YEAR ENDED DECEMBER 31, 2006
TABLE OF CONTENTS
i
Table of Contents
Special Note Regarding Forward Looking Statements
This Annual Report on Form 10-K and the documents we incorporate by reference herein include
forward-looking statements. All statements other than statements of historical facts contained in
this Form 10-K and the documents we incorporate by reference, including statements regarding our
future financial position, business strategy and plans and objectives of management for future
operations, are forward-looking statements. The words “believe,” “may,” “estimate,” “continue,”
“anticipate,” “intend,” “should,” “plan,” “could,” “target,” “potential,” “is likely,” “will,”
“expect” and similar expressions, as they relate to us, are intended to identify forward-looking
statements within the meaning of the “safe harbor” provisions of Section 27A of the Securities Act
of 1933, as
amended, and Section 21E of the Securities Exchange Act of 1934, as amended. We have based
these forward-looking statements largely on our current expectations and projections about future
events and financial trends that we believe may affect our financial condition, results of
operations, business strategy and financial needs.
These forward-looking statements are subject to a number of risks, uncertainties and
assumptions described in “Risk Factors” and elsewhere in this Annual Report on Form 10-K. In
addition, our past results of operations do not necessarily indicate our future results. Moreover,
the ready-mix concrete and the heavy highway construction business are very competitive and rapidly
changing. New risk factors emerge from time to time and it is not possible for us to predict all
such risk factors, nor can we assess the impact of all such risk factors on our business or the
extent to which any risk factor, or combination of risk factors, may cause actual results to differ
materially from those contained in any forward-looking statements.
Except as otherwise required by applicable laws, we undertake no obligation to publicly update
or revise any forward-looking statements or the risk factors described in this Annual Report on
Form 10-K or in the documents we incorporate by reference, whether as a result of new information,
future events, changed circumstances or any other reason after the date of this Annual Report on
Form 10-K. You should not rely upon forward-looking statements as predictions of future events or
performance. We cannot assure you that the events and circumstances reflected in the
forward-looking statements will be achieved or occur. Although we believe that the expectations
reflected in the forward-looking statements are reasonable, we cannot guarantee future results,
levels of activity, performance or achievements.
PART I
Item 1. Business
About Meadow Valley
Meadow Valley Corporation (the “Company,” “Meadow Valley,” “we,” “us” and “our”), based in
Phoenix, Arizona, is engaged in the construction industry as both a provider of construction
services and a supplier of construction materials. Our construction services segment (the “CSS”)
specializes in structural concrete construction of highway bridges and overpasses, and the paving
of highways and airport runways. The construction materials segment (the “CMS”) provides ready mix
concrete, sand and gravel products to both itself and primarily to other contractors. The
construction materials testing segment (the “CMTS”) provides geotechnical, environmental and field
and laboratory technical services to the construction industry. The CSS operates throughout
Nevada, Arizona and southern Utah. The CMS operates in the Las Vegas, Nevada and Phoenix, Arizona
metropolitan areas. The CMTS operates in the Las Vegas, Nevada regional area.
2006 Highlights
In terms of our financial performance, 2006 surpassed 2005 in nearly every category. Revenue
increased 6.3% compared to 2005, gross margin improved to 9.9% in 2006 from 8.3% in 2005 and net
income before minority interest increased 27.5% from $4.5 million in 2005 to $5.7 million in 2006.
Since the public offering of our materials segment company, Ready Mix, Inc. (“RMI”), was completed
on August 24, 2005, only four months of minority interest deduction impacted 2005 compared to a
full year of minority interest deduction in 2006. However, assuming the public offering would have
happened as of January 1, 2005 and making a pro forma comparison
1
Table of Contents
between 2005 and 2006, earnings per
share, on a fully diluted basis, would have increased 12.5% from $.80 in 2005 to $.90 in 2006.
The following table represents the proforma analysis of the impact of minority interest in
consolidated subsidiary:
| For the Years Ended December 31, | ||||||||
| 2006 | 2005 | |||||||
| (Pro forma) | ||||||||
Income before minority interest in
consolidated subsidiary |
$ | 5,729,371 | $ | 4,492,242 | ||||
Minority interest in consolidated subsidiary |
1,563,449 | 1,163,753 | ||||||
Net income |
$ | 4,165,922 | $ | 3,328,489 | ||||
Diluted net income per share |
$ | 0.90 | $ | 0.80 | ||||
Diluted weighted average shares outstanding |
4,621,124 | 4,151,096 | ||||||
RMI continued to invest in its existing markets by expanding its production and delivery
capacity with the addition of two new ready-mix concrete batch plants and thirty-four new ready-mix
transit mixers during the year. In addition, a second sand and gravel production facility in the
Las Vegas, Nevada vicinity was completed soon after the end of the year and is expected to provide
cost savings for raw materials used in the production of ready-mix concrete.
We negotiated an acceptable settlement to another construction contract claim that resulted in
receiving approximately $5.1 million in cash and decreasing our claim receivable by approximately
$1.8 million. The claim receivable reduction was offset somewhat by recording an additional $0.7
million claim receivable from the Gooseberry project which represents what we expect to eventually
collect on our $7.1 million claim that has now been submitted by the Company against the owner, the
Federal Highway Administration. We believe this number is a conservative estimate but we are
unable to predict at this time how long it may take to resolve the Gooseberry claim.
Our aggregate bonding capacity, that determines the cumulative value of construction contracts
that our services segment can accumulate at any given time, increased from $120 million at the
beginning of the year to $200 million at the end of the year. Our continued performance in
successfully and profitably completing contracts, a line of credit from our lender, as well as the
cash infusion resulting from our approximately $6.5 million private placement offering, were the
primary reasons for this increase. As a result of increasing bonding capacity throughout the year,
we were able to bid on 75% more dollar value of contracts in 2006 than in 2005. Our contract
backlog as of December 31, 2006 of $89.5 million is 31% higher than a year ago and, based upon our
increased bonding capacity, we expect to be able to bid on even more work during 2007 and thus,
potentially win more new contracts.
History
Meadow Valley Corporation was incorporated in Nevada on September 15, 1994. In October and
November 1995, we sold 1,926,250 Units of our securities to the public at $6.00 per Unit (the
“Public Offering”). Each Unit consisted of one share of $.001 par value common stock and one
common stock purchase warrant exercisable to purchase one additional share of common stock at $7.20
per share. These warrants expired unexercised on December 31, 2002.
We currently have three subsidiaries, MVCI and Apex Testing Corp. (“Apex”), which are wholly
owned, and RMI, of which we own 53%. MVCI was founded in 1980 as a heavy construction contractor
and has been providing construction services since inception. We purchased all of the outstanding
common stock of MVCI on October 1, 1994, therefore, references to our history includes the history
of MVCI.
Through MVCI, we provide construction services. MVCI operates as a heavy highway contractor
on both public and private infrastructure projects including the construction of bridges and
overpasses, channels, roadways,
2
Table of Contents
highways and airport runways. MVCI generally serves as the prime
contractor for public sector customers (such as federal, state and local governmental authorities)
in the states of Nevada, Arizona and southern Utah.
In 1996, we expanded into the construction materials segment of the construction industry with
the formation of RMI. RMI manufactures and distributes ready mix concrete, crushed landscaping
rock and other miscellaneous rock and sand products. RMI owns and operates seven ready mix
concrete batch plants – three in the Las Vegas, Nevada area, one in Moapa, Nevada and three in the
Phoenix, Arizona area and owns or leases approximately 180 ready mix trucks as well as a small
fleet of tractors and trailers used for hauling raw materials.
RMI operates three aggregate production facilities located in the vicinity of Las Vegas,
Nevada, that supplies approximately 95% of the total sand and gravel that are part of the raw
materials for the ready mix concrete that it manufactures and delivers. RMI ready mix batch plants
in the Phoenix, Arizona area are located on or near sand and gravel production sites operated by
third parties from whom RMI purchases sand and gravel. RMI primarily targets customers such as
concrete subcontractors, prime contractors, homebuilders, commercial and industrial property
developers and homeowners. RMI began its ready mix concrete operation from its first location in
North Las Vegas in March 1997, then began processing rock and sand from its Moapa pit in November
1999, and expanded into the Phoenix area with two plants in 2000. RMI successfully completed an
initial public offering in August 2005. We continue to own 2,025,000 shares of RMI, or
approximately 53%, of RMI’s 3,807,500 total shares outstanding.
Consistent with our dual interests in construction services and construction materials,
through MVCI we also own one portable hot mix asphalt plant, a rubberized asphalt plant, and
related asphalt paving equipment as well as a portable crushing and screening plant. The
portability of these plants provide us an opportunity to enhance our construction operations in our
existing markets, improve our competitiveness and generate increased revenues on projects that call
for large quantities of asphaltic concrete, recycled asphalt, or rubberized asphalt. These
capabilities will also open opportunities to provide construction materials or to subcontract our
services to other construction companies.
Our backlog (anticipated revenue from the uncompleted portions of awarded projects) was
approximately $89.5 million at December 31, 2006, compared to approximately $68.4 million at
December 31, 2005, and consists of various projects in Nevada and Arizona. Our entire backlog is
scheduled for completion during 2007. We have been the prime contractor on projects funded by a
number of governmental authorities, including the Federal Highway Administration, the Arizona
Department of Transportation, the Nevada Department of Transportation, the Clark County (Nevada)
Department of Public Works, the Utah Department of Transportation, the City of Phoenix, the Salt
Lake City (Utah) Airport Authority and the New Mexico State Highway and Transportation Department.
In the second quarter of 2006, we purchased the operating assets of the Las Vegas, Nevada
office of an existing materials testing company. We began operating this subsidiary as Apex
Testing Corp. Apex provides geotechnical, environmental and field and laboratory technical
services. Apex provides services to various contractors in all construction industries in the Las
Vegas, Nevada regional area.
Business Strategy
The business strategies we employ or are implementing include:
| • | Continuing to actively bid in the construction markets in Arizona and Nevada and improving construction project profitability. We will continue to focus our construction services within the geographic markets that have historically produced the best profits. Our emphasis is on building transportation infrastructure and other related heavy civil projects in our core markets of Arizona and Nevada. At the same time, we strive to improve margins on new contracts by, among other things, increasing, when possible, margins on new work bidding, maximizing labor and equipment productivity, negotiating more favorable material purchase contracts and employing the most competitive subcontractors. | ||
| • | Growing our client base for private construction services and ensuring satisfaction of existing private customer base. We have succeeded in attracting and retaining a nucleus of non-public clients for whom we regularly perform construction services. We believe we can generate better margins in the |
3
Table of Contents
| private sector, therefore we seek to grow our client base, add new customers and maintain continued customer satisfaction. | |||
| • | Continuing to increase working capital and liquidity. We strive to grow cash balances and employ available financing opportunities that will maximize working capital and liquidity. By doing so, we expect to increase bonding capacity, thereby allowing us to bid on more numerous or larger projects. | ||
| • | Continuing diligent pursuit of the successful resolution of three construction claims. Substantial costs were incurred in completing certain projects in New Mexico and Utah. We believe that much of the costs are reimbursable due to changed conditions, owners’ plan errors and omissions, conflicting utility right of ways and delays not attributable to us. As of December 31, 2006, the total amount of claims on the New Mexico and Utah projects that have been submitted and remain unpaid is approximately $19.1 million, of which $15.1 million represents our portion of the claims. | ||
| • | Implementing the growth strategy for Ready Mix, Inc. We will seek to enter new geographic sub-markets initially within the Phoenix and Las Vegas metropolitan areas. These markets will likely be located at the outer edges of the two metropolitan markets, but at a sufficient distance from these metropolitan markets so as to require the development of newer plants to service job sites in these areas. | ||
| • | Acquiring sand and gravel mining rights. A key strategy for the future growth and value of the construction materials segment is the acquisition of mining properties, either by purchase or lease whichever is most advantageous, to decrease dependency on third-party suppliers, to control production and to increase revenue from the sale of sand and gravel products. |
Market Overview
The construction market in the United States remains stable in spite of a decline in
residential construction activity. According to the U.S. Census Bureau, the total value of
construction spending in 2006 in the United States was $1.2 trillion or approximately a 4.8%
increase over 2005. Total residential construction spending decreased 1.9% from the previous year,
or approximately $12.0 billion, but was offset by non-residential construction spending that
increased by approximately $41.7 billion, or 16.2%. Highway construction spending increased
approximately $9.7 billion, or 14.8% from 2005 to 2006. According to FMI, a leading construction
industry consulting and investment banking firm, construction spending in 2007 is expected to
increase approximately 2.0%.
Certain sectors of the local construction markets we operate in influence our business more
than others. The residential sector, both single-family and multi-family, represents a primary
source of revenue for our construction materials segment as ready-mix concrete is a key
construction material used in home, apartment and condominium construction. The residential sector
is primarily driven by population and job growth. The development of new residential subdivisions
are invariably accompanied by new or improved streets, commercial, industrial and public buildings,
highways and utilities, all of which provide revenue opportunities for both our services and
materials segments. According to the Western Blue Chip Economic Forecast, total residential
construction in 2006 decreased approximately 13.3% and 1.2% in Arizona and Nevada, respectively
and, furthermore, is predicted to decline in 2007 approximately 6.8% and 0% in Arizona and Nevada,
respectively.
Because our business currently focuses primarily in Arizona and Southern Nevada, certain
demographic drivers, such as population growth, have significant impact on the local construction
market. According to projections from the U.S. Census Bureau, Nevada and Arizona rank #1 and #2,
respectively, in estimated population growth between 2000 and 2030. By 2030, Nevada is predicted
to grow 114.3%, Arizona 108.8% and Florida is third at 79.5%. More specifically, the populations
of Clark County, Nevada and Maricopa County, Arizona have increased 24.3% and 18.3% respectively
during the period from April 1, 2000 through July 1, 2005.
Both segments of our business have been, and will likely continue to be, affected by
increasing costs of raw materials and occasional scarce supply which have been impacted by both
domestic and international economic forces. Thus far, we have been successful in passing on rising
costs by increasing the prices of materials and services and have mitigated the impact of scarce
supply of raw materials by modifying our construction schedules
4
Table of Contents
and increasing our in-house
capabilities to transport our own raw materials. Because much of the funding of transportation
infrastructure comes from local sales and fuel taxes, any event that may impact the overall economy
that would decrease consumer spending or diminish fuel consumption would result in lower receipts
of tax dollars that, in turn, would diminish the availability of funding for transportation
infrastructure.
Construction Services Segment (“CSS”)
Operations
The CSS constructs highways, bridges, overpasses, airport runways and constructs other heavy
civil projects. From our Phoenix, Arizona corporate office and area offices in Phoenix, Arizona
and North Las Vegas, Nevada, we market (primarily by responding to solicitations for competitive
bids) and manage all of our projects. Project management is also located on-site to provide direct
supervision for operations.
We consider a number of factors when determining whether to bid on a project, including
profitability, the location of the project, likely competitors and our current and projected
workloads. We use a computer-based project estimating system which reflects our bidding and
construction experience and we perform detailed quantity take-offs from bidding documents, which we
believe helps identify a project’s risks and opportunities. We develop comprehensive estimates
with each project divided into phases and line items for which separate labor, equipment, material,
subcontractor and overhead cost estimates are compiled. Once a project begins, the estimate
provides us with a budget against which ongoing project costs are measured. There can be no
assurance that every project will attain its budgeted costs. A number of factors can affect a
project’s profitability including weather, availability of a quality workforce and actual
productivity rates. Each month the project manager updates the project’s projected performance at
completion by using actual costs-to-date and re-forecasted costs-to-complete for the balance of the
work remaining. Regular review of these estimated costs-at-completion reports allow project, area
and corporate management to be as responsive as possible to cost overruns or other problems that
may affect profitability.
We own or lease most of the equipment used in our business, including cranes, backhoes,
graders, loaders, trucks, trailers, pavers, rollers, construction material processing plants, batch
plants and related equipment. On occasion, equipment that we own may be rented on a short-term
basis to third parties. The net book value of our equipment in the CSS at December 31, 2006 was
approximately $9.9 million.
Our corporate management oversees operational and strategic issues and, through the corporate
accounting staff, provides administrative support services to area managers and individual project
management at the project site. The latter are responsible for planning, scheduling and budgeting
operations, equipment maintenance and utilization and customer satisfaction. Area managers and
project managers monitor project costs on a daily and weekly basis while corporate management
monitors such costs monthly.
Raw materials (primarily concrete, aggregate and steel) used in our operation are available
from a number of sources. There are usually a sufficient number of materials suppliers within our
market area to assure us of adequate competitive bids for supplying such raw materials. Generally,
we will obtain several bids from competing concrete, asphalt or aggregate suppliers whose reserves
of such materials will normally extend beyond the expected completion date of the project. Costs
for raw materials vary depending upon project duration, construction season, and other factors;
but, generally, prices quoted to us for raw materials are fixed for the project’s duration.
Projects and Customers
We perform work for both private and public owners. In the public sector, our principal
customers are the state departments of transportation in Nevada and Arizona as well as bureaus and
departments of municipal and county governments in those states. Since completing the final
contracts in New Mexico, we have ceased the CSS operation in New Mexico. In the private sector, we
perform work primarily for land developers. For the year ended December 31, 2006, revenue
generated from four projects in Nevada and Arizona represented approximately 22% of our
consolidated revenue, or 37% of the CSS revenue. The discontinuance of any projects, a general
economic downturn or a reduction in the number of projects let out for bid in any of the states in
which we operate could have a material adverse effect on our business, financial condition and
results of operations.
5
Table of Contents
For the years ended December 31, 2006, 2005 and 2004, we recognized a significant portion of
our consolidated revenue from the following customers (shown as an approximate percentage of
consolidated revenue):
| For the Years Ended December 31, | ||||||||||||
| 2006 | 2005 | 2004 | ||||||||||
Arizona Department of
Transportation (Public) |
20.9 | % | 21.0 | % | 24.1 | % | ||||||
Del Webb (Private) |
5.1 | % | 11.6 | % | 6.8 | % | ||||||
The Contract Process
Our projects are obtained primarily through competitive bidding and negotiations in response
to advertisements by federal, state and local government agencies and solicitations by private
parties. We submit bids after a detailed review of the project specifications, an internal review
of our capabilities and equipment availability and an assessment of whether the project is likely
to attain targeted profit margins. We own, lease, or are readily able to rent, most equipment
necessary to complete the projects upon which we bid. After computing estimated costs of the
project to be bid, we add our desired profit margin before submitting the bid. We believe that
success in the competitive bidding process involves (i) being selective on projects bid upon in
order to optimize use of resources, (ii) identifying projects which require our specific expertise,
(iii) becoming familiar with all aspects of the project to avoid costly bidding errors and (iv)
analyzing the local market to determine the availability and cost of labor and the degree of
competition. Since 1995, we have been awarded contracts on approximately 21% of the projects upon
which we have bid. A substantial portion of our revenue is derived from projects that involve
“fixed unit price” contracts under which we are committed to provide materials or services at fixed
unit prices (such as dollars per cubic yard of earth or concrete, or linear feet of pipe). The
unit price is determined by a number of factors including haul distance between the construction
site and the warehouses or supply facilities of local material suppliers and to or from disposal
sites, site characteristics and the type of equipment to be used. While the fixed unit price
contract generally shifts the risk of estimating the quantity of units for a particular project to
the customer, any increase in our unit cost over its unit bid price, whether due to inefficiency,
faulty estimates, weather, inflation or other factors, must be borne by us.
Most public sector contracts provide for termination of the contract at the election of the
customer. In such event we are generally entitled to receive a small cancellation fee in addition
to reimbursement for all costs we incurred on the project. Many of our contracts are subject to
completion requirements with liquidated damages assessed against us if schedules are not met. In
the past, these provisions have not materially adversely affected our business.
We are also obligated to perform work as directed to do so by the owner. If we believe the
directives to be outside the scope of the original bid documents, or if the physical conditions as
found on the project are different than provided in the bid documents, or for any variety of
reasons we believe the directive to perform the work creates costs that could not reasonably be
ascertained from the bid documents, the contract permits us to make a claim for equitable
adjustment to the contract price. Such equitable adjustment requests are often called contract
claims. The process for resolving claims may vary from one contract to another, but in general,
there is a process to attempt resolution at the project supervisory level or with higher levels of
management within the Company and the owner. Depending upon the terms of the contract, claim
resolution may employ a variety of resolution methods including mediation, arbitration, binding
arbitration, litigation or other methods. Regardless of the process, it is typical that when a
potential claim arises on a project, we fulfill the obligation to perform the work and must incur
the costs in doing so. We will not recoup the costs until the claim is resolved. It is not
uncommon for the claim resolution process to take months, or, if it entails litigation, years to
resolve.
Contracts often involve work periods in excess of one year. Revenue on uncompleted fixed price
contracts is recorded under the percentage-of-completion method of accounting. Revenue on
contracts is recognized when direct costs are incurred. A common construction industry practice is
for the customer to retain a portion of the project’s billings, generally not exceeding 10%, until
the project is completed satisfactorily and all of our obligations are paid.
We act as prime contractor on most of our construction projects and will subcontract certain
activities such as electrical, mechanical, guardrail and fencing, signing and signals, foundation
drilling, steel erection and other
6
Table of Contents
specialty work to others. As prime contractor, we bill the
customer for work performed and pay the subcontractors from funds received from the customer.
Occasionally we provide our services as a subcontractor to another prime contractor. As a
subcontractor, we will generally receive the same or similar profit margin as we would as a prime
contractor, although revenue to us will be smaller because we only contract a part of the project.
As a prime contractor, we are responsible for the performance of the entire contract, including
work assigned to subcontractors.
Accordingly, we are subject to liability associated with the failure of subcontractors to perform
as required under the contract. We occasionally require our subcontractors to furnish bonds
guaranteeing their performance, although affirmative action regulations require us to use our best
efforts to hire minority subcontractors for a portion of the project and some of these
subcontractors may not be able to obtain surety bonds. On average, we have not required
performance bonds for less than 10% of the dollar amount of our subcontracted work, but could
likely increase the percentage of bonded subcontractors in the future. We are generally aware of
the skill levels and financial condition of our subcontractors through our direct inquiry of the
subcontractors and contract partners of the subcontractors, as well as our review of financial
information provided by the subcontractors and third party reporting services including credit
reporting agencies and bonding companies.
In connection with public sector contracts, we are required to provide various types of surety
bonds guaranteeing our own performance. Our ability to obtain surety bonds depends upon our net
worth, liquid working capital, past performance, management expertise and other factors. Surety
companies consider such factors in light of the amount of our surety bonds then outstanding and the
surety companies’ current underwriting standards, which may change from time to time. See
“Insurance and Bonding.”
Backlog
Our backlog (anticipated revenue from the uncompleted portions of awarded projects) was
approximately $89.5 million at December 31, 2006, compared to approximately $68.4 million at
December 31, 2005. Much of our backlog depends upon our success in the competitive bid process.
Bidding strategies and priorities may be influenced and changed from time to time by the level of
our backlog and other internal and external factors. A portion of our anticipated revenue in any
year is not reflected in our backlog at the start of the year because some projects, or portions of
projects, are initiated and completed in the same fiscal year. Our entire backlog is scheduled for
completion during 2007. Revenue may be impacted in any one period by the backlog at the beginning
of the period. Accordingly, revenue in the future may be significantly reduced if we are unable
to obtain substantial new projects in 2007. We include a construction project in our backlog at
such time as a contract is awarded or a firm letter of commitment is obtained. We believe that our
backlog figures are firm, subject to provisions contained in some contracts, which allow customers
to modify or cancel the contracts at any time upon payment of a relatively small cancellation fee.
We have not been adversely affected by contract cancellations or modifications in the past.
Competition
We believe that the primary competitive factors as a prime contractor in the heavy
construction industry are price, reputation for quality work, financial strength, knowledge of
local market conditions and estimating abilities. We believe that we compete favorably with
respect to each of the foregoing factors on projects that we are able to bid. Most of our projects
involve public sector work for which contractors are first pre-qualified to bid and then are chosen
by a competitive bidding process, primarily on the basis of price. We compete with a large number
of small owner/operator contractors that tend to dominate smaller (under $4 million) projects.
When bidding on larger infrastructure projects, we also compete with larger, well capitalized
regional and national contractors, many of whom have larger net worth, higher bonding capacity and
more construction personnel. Larger competitors typically have unlimited bonding capacity and,
therefore, are able to bid on more work. Except for bonding capacity and liquidity, we contend
that we are not at a competitive disadvantage in relation to our larger competitors. With respect
to our smaller competitors, we believe that our current bonding capacity and long relationships
with subcontractors and suppliers may be a competitive advantage.
In the event of a decrease of work available in the private construction market, it is
foreseeable that contractors may exit the private market and enter the public market segment
resulting in increased competition.
7
Table of Contents
Insurance and Bonding
We carry builders risk insurance on a limited number of projects and depending upon our
assessment of individual project risk versus the cost of insurance.
We are required to provide a surety bond on nearly all publicly funded projects and on some
private projects. Our ability to obtain bonding, and the amount of bonding required, is primarily
determined by our experience, net worth, liquid working capital (consisting of cash and accounts
receivable in excess of accounts payable and accrued liabilities), our performance history, the
number and size of projects under construction and other factors. Surety companies consider such
factors in light of the amount of our surety bonds then outstanding and the surety companies’
current underwriting standards, which may change from time to time. The larger the project and/or
the more projects in which we are engaged, the greater our bonding, net worth and liquid working
capital requirements will be. Bonding requirements vary depending upon the nature of the project
to be performed. We generally pay a fee to bonding companies based upon the amount of the contract
to be performed. Because these fees are generally payable at the beginning of a project, we must
maintain sufficient working capital to satisfy the fee prior to receiving revenue from the project.
Operating losses in 2000 and 2001, due primarily to losses on contracts with New Mexico and Clark
County, Nevada, resulted in decreased liquidity and a change in our surety credit. Our current
bonding limits are consistent with our recent bidding activity, our single project bonding limit is
currently $50 million and our aggregate program maximum is $200 million. We believe our bonding
capacity will continue to improve commensurate with our ongoing performance and as bonding capacity
increases, so too will our bidding opportunities. Therefore, we believe that contract revenue will
increase as our bonding capacity increases, although no assurance can be given that we will
actually experience such results.
Marketing
Most of our contract revenue is from projects we obtain primarily through the process of
competitive bidding. Accordingly, for competitive bid projects our marketing efforts are limited
to subscribing to bid reporting services and monitoring trade journals and other industry sources
for bid solicitations by various governmental authorities. In response to a bid request, we submit
a proposal detailing our qualifications, the services to be provided and the cost of the services
to the soliciting entity which then, based on their evaluation of the proposals submitted, awards
the contract to the successful bidder. Generally, the contract for a project is awarded to the
lowest bidder, although other factors may be taken into consideration such as the bidder’s track
record for compliance with bid specifications and procedures and their construction experience.
The balance of our CSS work is obtained through negotiation or being included on a preferred
bidder’s list. We strive to constantly improve our relationships with such customers by being
responsive and building quality work.
Construction Materials Segment (“CMS”)
Operations
We began our construction materials operations in the first quarter of 1997 with the start-up
of RMI. RMI currently operates seven ready-mix concrete batch plants — three in the Las Vegas,
Nevada area, one in Moapa, Nevada and three in the Phoenix, Arizona area and approximately 180
ready-mix trucks. The CMS operates three aggregate production facilities located in the vicinity
of Las Vegas, Nevada, that supplies approximately 95% of the total sand and gravel that are part of
the raw materials for the ready mix concrete that it manufactures and delivers. Our ready-mix
batch plants in the Phoenix, Arizona area are located on or near sand and gravel production sites
operated by third parties from whom RMI purchases sand and gravel.
Projects and Customers
We target concrete subcontractors, prime contractors, homebuilders, commercial and industrial
property developers in the Las Vegas, Nevada and Phoenix, Arizona metropolitan areas. Revenue
generated from our top 10 CMS customers in Nevada and Arizona represented approximately 19% of our
consolidated revenue and represented 44% of the CMS’s revenue. The discontinuance of service to
any of the above referenced customers or a general economic downturn could have an adverse effect
on our future results of operations within this segment.
8
Table of Contents
For the years ended December 31, 2006,
2005 and 2004 we did not recognize a significant portion of our consolidated revenue from any
individual CMS customer.
Competition
The ready-mix concrete industry is highly competitive. Our ability to compete in our two
markets depends
largely on the proximity of our customers’ job sites to our ready-mix concrete plant
locations, our plant operating costs and the prevailing ready-mix concrete prices in each market.
Price is the primary competitive factor among suppliers for small or simple jobs, principally in
residential construction, while timeliness of delivery and consistency of quality and service as
well as price are the principal competitive factors among suppliers for large or complex jobs. Our
competitors range from small, owner-operated private companies to subsidiaries or operating units
of large, vertically integrated cement manufacturing and concrete products companies.
Our direct competitors include Rinker Materials, Nevada Ready Mix and Silver State Materials
in Nevada and Rinker Materials, Cemex, Vulcan Materials and Hanson Materials in Arizona. We also
face significant competition from many smaller ready-mix concrete providers. We believe we compete
favorably with all of our competitors due to our plant locations, quality of our raw materials, our
delivery and service, and our competitive prices. However, competitors having lower operating costs
than we do or having the financial resources to enable them to accept lower margins than we do have
competitive advantages over us for jobs that are particularly price-sensitive. Moreover,
competitors having greater financial resources to invest in new mixer trucks or build plants in new
areas than we do also have competitive advantages over us.
Marketing
General contractors and subcontractors typically select their suppliers of ready-mix concrete.
In large, complex projects, an engineering firm or division within a state transportation or public
works department may influence the purchasing decision, particularly where the concrete has
complicated design specifications. In those projects and in government-funded projects generally,
the general contractor or subcontractor usually awards supply orders on the basis of either direct
negotiation or competitive bidding. We believe that the purchasing decision in many cases
ultimately is relationship-based. Our marketing efforts target general contractors, concrete
subcontractors, design engineers and architects whose focus extends beyond the price of ready-mix
concrete to product quality and consistency and reducing their in-place cost of concrete.
The CMS currently has 10 full-time sales persons. We also intend to develop and implement
training programs to increase the marketing and sales expertise and technical abilities of our
staff. Our goal is to maintain a sales force whose service-oriented approach will appeal to our
targeted prospective customers and differentiate us from our competitors.
Construction Materials Testing Segment (“CMTS”)
Operations
We began our construction materials testing operations in the second quarter of 2006 with the
start-up of Apex Testing Corp. The CMTS currently operates a full service regional construction
materials testing office in the Las Vegas, Nevada area. The CMTS provides geotechnical,
environmental and field and laboratory technical services. The CMTS provides these services to a
variety of customers in the Las Vegas, Nevada regional area.
Projects and Customers
The CMTS targets customers in all industries of construction contracting. Current customers
include residential home builders, commercial contractors, public works prime contractors and
actual owners of various projects. The discontinuance of service to any of the above referenced
customers or a general economic downturn could have an adverse effect on our future results of
operations within this segment. For the year ended December 31, 2006, we did not recognize a
significant portion of our consolidated revenue from any individual CMTS customer.
9
Table of Contents
Competition
The construction materials testing industry is very competitive. Our ability to compete for
basic soil or concrete slab testing, principally in residential construction, inspection expertise
and consistency of quality and service as well as price are the principal competitive factors for
large public works projects or complex jobs. Our competitors range from small, owner-operated
private companies to subsidiaries or operating units of large,
vertically integrated engineering and testing firms.
Marketing
General contractors and subcontractors typically select their materials testing firms. In
large, complex projects, materials testing firms need to be pre-qualified to be eligible to
maintain the quality control program of a project, particularly where the concrete, or other
construction materials have complicated design specifications. In those projects and in
government-funded projects generally, the general contractor or subcontractor usually awards the
materials testing and quality control portion of the project on the basis of either direct
negotiation or competitive bidding. We believe that the purchasing decision in many cases
ultimately is relationship-based. Our marketing efforts target general contractors, concrete
subcontractors, design engineers, land developers and owners whose focus extends beyond the price
of professional services to expert inspection and supervision of the quality control process.
The CMTS currently has one professional engineer who is licensed in both Utah and Nevada. He
is also a certified environmental manager in the State of Nevada, and a certified underground
storage tank consultant in the State of Utah. We have one engineer-in-training and one graduate
engineer who is also a certified soil and groundwater sampler in the State of Utah. There are 11
field inspectors as well as three certified laboratory technicians. We also intend to develop and
implement training programs to increase the geotechnical and environmental expertise and technical
abilities of our field staff. Our goal is to maintain a field inspection and technician staff whose
service-oriented approach will appeal to our targeted prospective customers and differentiate us
from our competitors.
Meadow Valley Corporation and our Segments
Seasonality
The construction industry is seasonal, generally due to inclement weather and length of
daylight hours occurring in the winter months. Accordingly, we may experience a seasonal pattern
in our operating results with lower revenue in the first and fourth quarters of each calendar year
than other quarters. Quarterly results may also be affected by the timing of bid solicitations by
governmental authorities, the stage of completion of major projects and revenue recognition
policies. Results for any one particular quarter, therefore, may not be indicative of results for
other quarters or for the year.
Insurance
We maintain general liability and excess liability insurance covering our owned and leased
construction equipment and workers’ compensation insurance in amounts we believe are consistent
with our risks of loss and in compliance with specific insurance coverage required by our customers
as a part of the bidding process. We carry liability insurance of $11 million per occurrence,
which we believe is adequate for our current operations and consistent or greater than the
requirements of projects currently under construction by our construction services segment.
Government Regulation
Our operations are subject to compliance with regulatory requirements of federal, state and
municipal authorities, including regulations covering labor relations, safety standards,
affirmative action and the protection of the environment including requirements in connection with
water discharge, air emissions and hazardous and toxic substance discharge. Under the Federal
Clean Air Act and Clean Water Act, we must apply water or chemicals to reduce dust on road
construction projects and to contain water contaminants in run-off water at construction sites.
10
Table of Contents
We may also be required to hire subcontractors to dispose of hazardous wastes encountered on a
project. We believe that we are in substantial compliance with all applicable laws and
regulations. However, future amendments to current laws or regulations imposing more stringent
requirements could have a material adverse effect on us.
Employees
At March 1, 2007, we employed approximately 83 salaried employees (including our management
personnel and executive officers) and approximately 400 hourly employees. The number of hourly
employees varies depending upon the amount of construction in progress. During the year ended
December 31, 2006, the number of hourly employees ranged from approximately 471 to approximately
575 and averaged approximately 522. None of our employees belong to a labor union and we believe
our relationship with our employees is satisfactory.
Website Access
Our website address is www.meadowvalley.com. On our website we make available, free of
charge, our annual report on Form 10-K, our most recent quarterly reports on Form 10-Q, current
reports on Form 8-K, Forms 3, 4, and 5 related to beneficial ownership of our securities, code of
ethics and all amendments to those reports as soon as reasonably practicable after such material is
electronically filed with or furnished to the United States Securities and Exchange Commission.
The information on our website is not incorporated into, and is not part of, this report.
Item 1A. Risk Factors
The risk factors listed in this section and other factors noted herein or incorporated by
reference could cause our actual results to differ materially from those contained in any
forward-looking statements. The following risk factors, in addition to the information discussed
elsewhere herein, should be carefully considered in evaluating us and our business:
Dependence on Public Sector Customers. Substantially all of our revenue is generated from
projects sponsored by federal, state and local governmental authorities. Consequently, any
reduction in demand for our services by these governmental authorities for whatever reason,
including a general economic slowdown or a continuation of the current trend toward reducing
governmental spending, would have a material adverse effect on our business, financial condition
and results of operations. Furthermore, government contracts are generally terminable at will,
subject to a relatively small cancellation payment.
Liability for Subcontractor Performance. We act as prime contractor on most of our
construction projects and are therefore responsible for performance of the entire contract,
including work assigned to subcontractors. Accordingly, we may be subject to substantial liability
if a subcontractor fails to perform as required under the prime contract.
Fixed Unit Price Risks. A substantial portion of our revenue is derived from “fixed unit
price” contracts under which we are committed to provide materials or services at fixed unit prices
(such as dollars per cubic yard of earth or concrete). While fixed unit price contracts generally
shift the risk of estimating the quantity of units required for a particular project to our
customers, any increase in our unit cost over our unit bid price, whether due to inefficiency,
faulty estimates, weather, inflation or other factors, must be borne by us and may have a material
adverse effect on our business, financial condition and results of operations.
Variations in Quarterly Operating Results. The construction industry is seasonal, generally
due to inclement weather occurring in the winter months. Accordingly, we generally experience a
seasonal pattern in our operating results with lower revenue in the first and fourth quarters of
each calendar year than other quarters. Quarterly results may also be affected by the timing of
bid solicitations by governmental authorities and the stage of completion of major projects.
Results for any one quarter, therefore, may not be indicative of results for other quarters or for
the entire year.
Potential Liability for Environmental Damages and Personal Injury. The construction industry
is subject to significant risks of statutory, contractual and common law liability for
environmental damages and personal injury. We may be liable for claims arising from our on-site or
off-site services, including mishandling of hazardous
11
Table of Contents
or non-hazardous waste materials, or
environmental contamination caused by us or our subcontractors, the costs for which could be
substantial, even if we exercised due care and complied with all relevant laws and regulations. We
are also subject to worker and third party claims for personal injury resulting in substantial
liability for which we may be uninsured. We carry insurance which we consider sufficient to meet
regulatory and customer requirements and to protect our assets and operations. Nevertheless, an
uninsured claim against us could have a material adverse effect on our business, financial
condition and results of operations. Moreover, any inability to obtain insurance of
the type and in the amounts required in connection with specific projects could impair our ability
to bid on or complete such projects.
An Inability to Secure and Permit Aggregate Reserves Could Negatively Impact Our Future
Operations and Results. Tighter regulations for the protection of the environment and the finite
nature of property containing suitable aggregate reserves are making it increasingly challenging
and costly to secure and permit aggregate reserves. Although we have thus far been able to secure
and permit reserves to support our business, it is likely to become increasingly difficult to do
so, and there is no assurance that we will be able to secure and permit reserves in the future.
We Are Subject to Significant Bonding Requirements. We are required to provide bid and/or
performance bonds in connection with governmental construction projects. Our current bonding
limits are approximately $200 million in the aggregate and $50 million per project, but there can
be no assurance that we will be able to maintain these bonding limits. In addition, new or
proposed legislation in various jurisdictions may require the posting of substantial additional
bonds or require other financial assurances for particular projects. As a result of our bonding
limits, we are restricted in the number and size of projects we may concurrently bid on, which may
affect our results of operations.
We Are Subject to Regulation. Our operations are subject to compliance with regulatory
requirements of federal, state and municipal authorities, including regulations covering labor
relations, safety standards, affirmative action and the protection of the environment, including
requirements in connection with water discharge, air emissions and hazardous and toxic substance
discharge. We believe that we are in substantial compliance with all applicable laws and
regulations. However, amendments to current laws and regulations imposing more stringent
requirements could have a material adverse effect on us.
There Are Risks Associated with Concentration of Construction Projects and Customers. Our
operations are primarily situated in the states of Arizona and Nevada. The discontinuance of any
projects in these states, a general economic downturn or a reduction, as a result of market
conditions, in the number of projects let out for bid in these two states, could have a material
adverse effect on our business, financial condition and results of operations.
We Face Intense Competition. Our business and industry are intensely competitive. We compete
with a large number of small owner/operator contractors that tend to dominate smaller highway
projects, together with larger, well capitalized regional and national contractors, when bidding on
larger infrastructure projects. Moreover, due to currently favorable market conditions in our
market areas, additional competition for projects continues to develop. Such additional
competition could reduce our profit margins on our projects.
Our Success Depends on Attracting and Retaining Qualified Personnel in a Competitive
Environment. The single largest factor in our ability to profitably execute our work is our
ability to attract, develop and retain qualified personnel. Our success in attracting qualified
people is dependent on the resources available in the individual geographic areas in which we
operate and the impact on the labor supply due to general economic conditions as well as our
ability to provide a competitive compensation package and work environment.
Dependence Upon Executive Officers. Our operations are dependent upon the continued services
of our executive officers. The loss of services of any of our executive officers, whether as a
result of death, disability or otherwise, could have a material adverse effect upon our operations.
We have employment agreements with our executive officers and carry key person insurance on their
lives.
Strikes or Work Stoppages Could Have a Negative Impact on Our Operations and Results. Strikes
or work stoppages by labor unions or attempts to unionize our workers could have a significant
negative impact on us.
12
Table of Contents
Unavailability of Insurance Coverage Could Have A Negative Impact on Our Operations and
Results. We maintain insurance coverage as part of our overall risk management strategy and due to
requirements to maintain specific coverage in our financing agreements and in most of our
construction contracts. Although we have been able to obtain insurance coverage to meet our
requirements in the past, there is no assurance that such insurance coverage will be available in
the future.
We Use Diesel Fuel, Asphalt Oil and Other Petroleum Based Products That Are Subject To
Significant Price Fluctuations. These materials are used to run our equipment and are a
significant part of the asphalt paving materials that are used in many of our construction
projects. Although we can be partially protected by asphalt or fuel escalation clauses in some of
our contracts, not all contracts provide such protection.
Item 1B. Unresolved Staff Comments
None.
Item 2. Properties
We owned or leased the following properties at December 31, 2006:
| Approximate | Approximate | |||||||||||||||||||
| Building Size in | Land | Owned/ | Monthly | Lease | ||||||||||||||||
| Location | Segment | Purpose | Square Feet | in Acres | Leased | Rental | Expires | |||||||||||||
4602 East Thomas Road, Phoenix, Arizona |
CSS, CMS | Corporate office, Area office |
18,400 | 2 | Owned | — | — | |||||||||||||
3430 East Flamingo Suite 100, Las Vegas, Nevada |
CMS | Area office | 3,500 | — | Leased | $ | 8,230 | 04/30/2007 | ||||||||||||
2250 West Center Street, Springville, Utah |
CSS | Field office | 1,600 | — | Leased | $ | 2,370 | 04/30/2008 | ||||||||||||
4635 Andrews Street, North Las Vegas, Nevada |
CSS | Area office | 4,320 | — | Leased | $ | 3,906 | 09/30/2009 | ||||||||||||
109 West Delhi, North Las Vegas, Nevada |
CMS | Ready Mix production facility |
4,470 | 5 | Owned | — | — | |||||||||||||
11500 West Beardsley Road, Sun City, Arizona (1) |
CMS | Ready Mix production facility |
440 | 5 | Leased | — | 05/31/2010 | |||||||||||||
39245 North Schnepf Road, Queen Creek, Arizona |
CMS | Ready Mix production facility |
440 | 5 | Owned | — | — | |||||||||||||
Richmar Ave., Las Vegas, Nevada |
CMS | Ready Mix production facility |
440 | 5 | Owned | — | — | |||||||||||||
6210 Annie Oakley Drive Suite
102, Las Vegas, Nevada |
CSS | Field office | 1,000 | — | Leased | $ | 1,200 | 03/31/2009 | ||||||||||||
Moapa, Nevada (1)
|
CMS | Sand and Aggegate production facility | 840 | 40 | Leased | — | 01/01/2009 | |||||||||||||
Moapa, Nevada (1)
|
CMS | Ready Mix production facility |
440 | — | Leased | — | — | |||||||||||||
Northwest Arizona (1)
|
CMS | Sand and Aggegate production facility | 840 | 40 | Leased | — | 08/27/2007 | |||||||||||||
Northwest Las Vegas, Nevada (1)
|
CMS | Sand and Aggegate production facility | — | 40 | Leased | — | 04/30/2007 | |||||||||||||
Northwest Las Vegas, Nevada (1)
|
CMS | Ready Mix production facility |
440 | — | Leased | — | — | |||||||||||||
3155 East Patrick Lane Suite
#12, Las Vegas, Nevada |
CMTS | Area office, laboratory facility |
3,300 | — | Leased | $ | 2,898 | 12/31/2007 | ||||||||||||
| (1) | - Our facility rent is included in the cost of the material which we purchase from the lessors. |
Our CSS may lease office space on a short-term basis based on location, duration, and the
availability of facilities at our ongoing construction sites. We have determined that the above
properties are sufficient to meet our current needs. We will continue to search for possible
additional site locations to expand our operations if market conditions warrant.
13
Table of Contents
Item 3. Legal Proceedings
See Note 17 — Litigation and Claim Matters in the accompanying consolidated financial
statements (Item 8) for information regarding material legal proceedings.
Item 4. Submission of Matters to a Vote of Security Holders
There were no matters submitted to a vote of security holders, through the solicitation of
proxies or otherwise, during the fourth quarter of the year ended December 31, 2006.
PART II
Item 5. Market for Registrant’s Common Equity and Related Stockholder Matters
Meadow Valley Corporation’s common stock was listed on the Nasdaq National Market from October
1995 to August 2001. In August 2001, our securities were transferred to the Nasdaq SmallCap Market
and trade under the symbol “MVCO.” This market has since been renamed the Nasdaq Capital Market.
The following table represents the high and low closing prices for our common stock on the Nasdaq
Capital Market. As of March 6, 2007, there were approximately 1,200 record and beneficial owners
of our common stock. On March 6, 2007, our common stock closed at $12.89 per share.
| 2006 * | 2005 * | |||||||||||||||
| High | Low | High | Low | |||||||||||||
First Quarter |
$ | 15.59 | $ | 11.12 | $ | 7.35 | $ | 3.96 | ||||||||
Second Quarter |
12.35 | 10.13 | 7.20 | 4.56 | ||||||||||||
Third Quarter |
12.34 | 8.78 | 11.95 | 6.34 | ||||||||||||
Fourth Quarter |
10.80 | 9.80 | 14.26 | 7.88 | ||||||||||||
| * | - The quarterly highs and lows are based on daily market closing prices during each respective period. |
We have never declared or paid cash dividends on our common stock and do not anticipate
paying cash dividends in the foreseeable future. Any future determination to pay cash dividends
will be at the discretion of our Board of Directors and will be dependent upon our financial
condition, results of operations, capital requirements, general business conditions and other such
factors as our Board of Directors deems relevant.
| Equity Compensation Plan Information | ||||||||||||
| Number of securities | ||||||||||||
| remaining available | ||||||||||||
| Number of securities | for future issuance | |||||||||||
| to be issued upon | Weighted-average | under equity | ||||||||||
| exercise of | exercise price of | compensation plans | ||||||||||
| outstanding options, | outstanding options, | (excluding securities | ||||||||||
| Plan category | warrants and rights | warrants and rights | reflected in column (a)) | |||||||||
| (a) | (b) | (c) | ||||||||||
Equity compensation
plans approved by
security holders (1) |
434,542 | 4.86 | 90,149 | |||||||||
Equity compensation
plans not approved
by security holders |
— | — | ||||||||||
Total |
434,542 | 90,149 | ||||||||||
| (1) | - Includes 434,542 stock options issued to employees, directors and consultants from the 2004 equity incentive plan. |
14
Table of Contents
Our approved equity compensation plan, which we refer to as the 2004 Plan, permits the
granting of any or all of the following types of awards: (1) incentive and nonqualified stock
options, (2) stock appreciation rights, (3) stock awards, restricted stock and stock units, and (4)
other stock or cash-based awards. In connection with any award or any deferred award, payments may
also be made representing dividends or their equivalent.
We have reserved 1,200,000 shares of our common stock for issuance under the 2004 Plan. As of
December 31, 2006, 90,149 shares were available for future grant under the 2004 Plan. The term of
the stock options is five or ten years and may be exercised after issuance as follows: 33.3% after
one year of continuous service, 66.6% after two years of continuous service and 100% after three
years of continuous service. The exercise price of each option is equal to the market price of the
Company’s common stock on the date of grant.
RMI also maintains equity compensation plan as follows:
| Equity Compensation Plan Information | ||||||||||||
| Number of securities | ||||||||||||
| remaining available | ||||||||||||
| Number of securities | for future issuance | |||||||||||
| to be issued upon | Weighted-average | under equity | ||||||||||
| exercise of | exercise price of | compensation plans | ||||||||||
| outstanding options, | outstanding options, | (excluding securities | ||||||||||
| Plan category | warrants and rights | warrants and rights | reflected in column (a)) | |||||||||
| (a) | (b) | (c) | ||||||||||
Equity compensation
plans approved by
security holders (1)(2) |
466,875 | 11.47 | 324,375 | |||||||||
Equity compensation
plans not approved
by security holders |
— | — | ||||||||||
Total |
466,875 | 324,375 | ||||||||||
| (1) | - Includes an individual compensation agreement for 116,250 warrants issued to our underwriters as a portion of their compensation in connection with our initial public offering. | |
| (2) | - Includes 350,625 stock options issued to employees, directors and consultants from our 2005 equity incentive plan. |
RMI’s approved equity compensation plan, which we refer to as the 2005 Plan, permits the
granting of any or all of the following types of awards: (1) incentive and nonqualified stock
options, (2) stock appreciation rights, (3) stock awards, restricted stock and stock units, and (4)
other stock or cash-based awards. In connection with any award or any deferred award, payments may
also be made representing dividends or their equivalent.
RMI has reserved 675,000 shares of its common stock for issuance under the 2005 Plan. As of
December 31, 2006, 324,375 shares were available for future grant under the 2005 Plan. The term of
the stock options are five years and may be exercised after issuance as follows: 33.3% after one
year of continuous service, 66.6% after two years of continuous service and 100% after three years
of continuous service. The exercise price of each option is equal to the market price of RMI’s
common stock on the date of grant.
We sold 817,120 unregistered securities on October 23, 2006. Each security or unit consisted
of one share of common stock, par value $.001 per share of Meadow Valley Corporation stock and one
tenth of a warrant to purchase one share of common stock, $.001 par value per share. The exercise
price of each warrant is $12.60 and the warrants are exercisable six months and a day from October
23, 2006 with the exercise period ending October 19, 2011. Each unit was sold for $9.00 and
proceeds net of offering costs were approximately $6.6 million. The proceeds were used as working
capital in order to secure additional bonding capacity. The securities were offered to accredited
investors in reliance on Section 4(2) of the Securities Act and Rule 506 promulgated thereunder.
Wunderlich Securities, Inc. served as our placement agent. The registration of these securities
became effective on November 17, 2006.
We did not repurchase any of our equity securities during 2006.
15
Table of Contents
The graph below compares the cumulative five year total return of holders of Meadow Valley
Corporation’s common stock with the cumulative total returns of the NASDAQ Composite Index, and
the Dow Jones US Heavy Construction Index. The graph tracks the performance of a $100 investment
in our common stock and in the two comparative indices (with the reinvestment of all dividends)
from 12/31/2001 to 12/31/2006.
COMPARISON
OF 5 YEAR CUMULATIVE TOTAL RETURN*
Among Meadow Valley Corporation, The NASDAQ Composite Index
And The Dow Jones US Heavy Construction Index
Among Meadow Valley Corporation, The NASDAQ Composite Index
And The Dow Jones US Heavy Construction Index
| * | $100 invested on 12/31/01 in stock or index-including
reinvestment of dividends. Fiscal year ending December 31. |
| 12/31/2001 | 12/31/2002 | 12/31/2003 | 12/31/2004 | 12/31/2005 | 12/31/2006 | |||||||||||||||||||||||||||
Meadow Valley Corporation |
100.00 | 40.00 | 87.69 | 204.10 | 593.85 | 520.51 | ||||||||||||||||||||||||||
NASDAQ Composite Index |
100.00 | 71.97 | 107.18 | 117.07 | 120.50 | 137.02 | ||||||||||||||||||||||||||
Dow Jones US Heavy Construction Index |
100.00 | 83.87 | 114.41 | 138.74 | 200.48 | 250.08 | ||||||||||||||||||||||||||
The stock price performance included in this graph is not necessarily indicative of future stock
price performance.
16
Table of Contents
Item 6. Selected Financial Data
Statement of Operations Information:
The selected financial data as of and for each of the five years ended December 31, 2006, are
derived from our consolidated financial statements and should be read in conjunction with the
consolidated financial statements included elsewhere in this Annual Report on Form 10-K and the
related notes thereto and “Management’s Discussion and Analysis of Financial Condition and Results
of Operations.”
| Years Ended December 31, | ||||||||||||||||||||
| 2006 | 2005 | 2004 | 2003 | 2002 | ||||||||||||||||
Statement of Operations Data: |
||||||||||||||||||||
Revenue |
$ | 195,521,951 | $ | 183,872,863 | $ | 166,831,664 | $ | 154,106,865 | $ | 151,047,268 | ||||||||||
Gross profit |
19,310,088 | 15,187,579 | 6,967,790 | 6,343,618 | 7,531,597 | |||||||||||||||
Income (loss) from operations |
8,148,269 | 6,521,006 | 457,951 | (150,667 | ) | 932,657 | ||||||||||||||
Income before income taxes
and minority interest |
8,893,156 | 7,063,197 | 890,443 | 162,381 | 936,770 | |||||||||||||||
Net income |
4,165,922 | 4,203,719 | 573,639 | 91,635 | 566,803 | |||||||||||||||
Basic net income per common share |
$ | 0.96 | $ | 1.11 | $ | 0.16 | $ | 0.03 | $ | 0.16 | ||||||||||
Diluted net income per common share |
$ | 0.90 | $ | 1.01 | $ | 0.15 | $ | 0.03 | $ | 0.16 | ||||||||||
Basic weighted average common shares
outstanding |
4,328,160 | 3,783,089 | 3,601,250 | 3,593,102 | 3,559,938 | |||||||||||||||
Diluted weighted average common shares
outstanding |
4,621,124 | 4,151,096 | 3,780,597 | 3,599,259 | 3,559,938 | |||||||||||||||
Dividends |
— | — | — | — | — | |||||||||||||||
Financial Position Data: |
||||||||||||||||||||
Working capital |
$ | 27,255,590 | $ | 21,913,277 | $ | 2,294,162 | $ | 5,757,671 | $ | 2,701,266 | ||||||||||
Total assets |
102,105,655 | 87,016,530 | 65,328,832 | 55,366,528 | 57,434,203 | |||||||||||||||
Long-term debt |
13,996,482 | 11,858,042 | 11,785,816 | 8,084,793 | 11,132,310 | |||||||||||||||
Stockholders’ equity |
31,341,214 | 19,795,787 | 12,716,188 | 12,142,549 | 12,050,914 | |||||||||||||||
Item 7. Management’s Discussion and Analysis of Financial Condition and Results of Operations
The following discussion of our results of operations and financial condition should be read
in conjunction with our consolidated financial statements and notes thereto included elsewhere
herein. Historical results and percentage relationships among accounts are not necessarily an
indication of trends in operating results for any future period. In these discussions, most
percentages and dollar amounts have been rounded to aid presentation. As a result, all such figures
are approximations.
Executive Overview
Our performance continues to steadily improve as a result of our decisions to:
| • | focus on the construction markets of Nevada, southern Utah and Arizona which have historically been more profitable for us, | ||
| • | be selective in the projects we choose to bid, provide incentives and reward outstanding project management, | ||
| • | concentrate our efforts to prevail in our past construction claims and eliminate distractions from lingering claims as well as to avoid future claims, | ||
| • | gradually increase our bonding capacity in order to bid on larger single projects and increase our contract backlog to levels that provide more sustainable momentum, and | ||
| • | implement expansion plans for our materials segment and focus marketing efforts on non-residential market sector. |
17
Table of Contents
Results of Operations
The following table sets forth statement of operations data expressed as a percentage of
revenue for the periods indicated:
| For the Years Ended December 31, | ||||||||||||||||||||||||
| (dollars in thousands) | 2006 | 2005 | 2004 | |||||||||||||||||||||
Revenue: |
||||||||||||||||||||||||
Construction services |
$ | 111,936 | 57.3 | % | $ | 116,822 | 63.5 | % | $ | 108,169 | 64.8 | % | ||||||||||||
Construction materials |
83,152 | 42.5 | % | 67,051 | 36.5 | % | 58,663 | 35.2 | % | |||||||||||||||
Construction materials testing |
434 | 0.2 | % | — | 0.0 | % | — | 0.0 | % | |||||||||||||||
Total revenue |
195,522 | 100.0 | % | 183,873 | 100.0 | % | 166,832 | 100.0 | % | |||||||||||||||
Gross profit |
19,310 | 9.9 | % | 15,188 | 8.3 | % | 6,968 | 4.2 | % | |||||||||||||||
General and administrative
expenses |
11,162 | 5.7 | % | 8,667 | 4.7 | % | 6,510 | 3.9 | % | |||||||||||||||
Income from operations |
8,148 | 4.2 | % | 6,521 | 3.6 | % | 458 | 0.3 | % | |||||||||||||||
Interest income |
1,010 | 0.5 | % | 563 | 0.3 | % | 86 | 0.1 | % | |||||||||||||||
Interest expense |
(339 | ) | -0.2 | % | (362 | ) | -0.2 | % | (348 | ) | -0.2 | % | ||||||||||||
Other income |
74 | 0.0 | % | 342 | 0.2 | % | 695 | 0.4 | % | |||||||||||||||
Income tax expense |
3,164 | 1.6 | % | 2,571 | 1.4 | % | 317 | 0.2 | % | |||||||||||||||
Minority interest in consolidated
subsidiary |
1,563 | 0.8 | % | 289 | 0.2 | % | — | 0.0 | % | |||||||||||||||
Net income |
$ | 4,166 | 2.1 | % | $ | 4,204 | 2.3 | % | $ | 574 | 0.3 | % | ||||||||||||
Depreciation and
amortization |
$ | 5,885 | 3.0 | % | $ | 4,499 | 2.4 | % | $ | 3,202 | 1.9 | % | ||||||||||||
Year Ended December 31, 2006 Compared to Year Ended December 31, 2005
Revenue and Backlog. Consolidated revenue improved 6.3% to $195.5 million for the year ended
December 31, 2006, as further referred to as “2006,” from $183.9 million for the year ended
December 31, 2005, as further referred to as “2005.” The improved revenue resulted from a $16.1
million increase, net of inter-company sales, from the CMS, offset by a decrease in revenue from
the CSS of $4.9 million. The CMS increase in revenue resulted from a 15.6% increase in the average
unit sales price in 2006 from 2005, complemented by an 8.2% increase in sales of cubic yards of
concrete which we refer to as “units”. Backlog in the CSS increased to $89.5 million compared to
$68.4 million a year ago. The beginning backlog in the CSS contributed to the decreased revenue in
2006, based on the progress schedules and nature of the contracts contained in the backlog at the
beginning of 2006. Because so much of our business stems from competitively bid public works,
backlog will fluctuate depending upon the amount and type of contracts that we bid on and win. Bid
bonds provided by our surety company are required on most of the contracts that we bid, therefore,
any restrictions or limitations in the extension of surety credit can impact the amount and type of
contracts available to be bid by our CSS. Surety credit limits and conditions may improve as our
financial performance improves, but there can be no assurance that surety credit will be increased.
Gross Profit. Consolidated gross profit increased to $19.3 million for 2006 from $15.2 million
for 2005 and consolidated gross margin, as a percent of revenue, increased to 9.9% in 2006 from
8.3% in 2005. Gross profit from CSS increased to $10.1 million in 2006 from $8.1 million in 2005
and the gross profit margin increased to 9.0% from 7.0% in the respective periods. Gross profit
margins are affected by a variety of factors including, the quality and accuracy of the initial
estimate, construction delays and difficulties due to weather or other conditions, availability of
materials, the timing of work performed by other subcontractors and the physical and geological
condition of the construction site. Gross profit from the CMS increased to $9.2 million in 2006
from $7.1 million in 2005 and the gross profit margin increased to 11.1% from 10.6% in the
respective periods. The increases in gross profit and gross profit margin during 2006 resulted
primarily from the expansion of the CMS operation and utilizing new equipment placed in service.
During 2007 we anticipate under-utilizing new equipment recently placed in service, but long-term
margins will benefit from our expansion efforts. The CMS fixed costs will increase in 2007
18
Table of Contents
as a result of our expansion efforts and could impact the CMS gross profit margins in the interim as we
bring this equipment up to full utilization.
Depreciation and Amortization. Depreciation and amortization expense increased to $5.9
million for 2006 from $4.5 million in 2005. The increase resulted from additional plant, equipment
and vehicles we placed in service during 2006. Of the $5.9 million for 2006, $3.4 million was from
our construction materials segment, while $2.5 million came from our construction services segment.
General and Administrative Expenses. General and administrative expenses increased to $11.2
million for 2006 from $8.7 million for 2005. This increase was primarily attributable to a $0.4
million increase in incentive compensation, a $0.7 million increase in payroll and payroll related
expenses and taxes, increases of $0.3 million in insurance premiums, accounting, computer and
consulting expenses, $0.2 million in legal fees, increases in public company expenses of $0.2
million, increase of $0.3 million in bad debt expense and increases of $0.2 million in utilities
and office expenses.
Interest Income, Expense and Other Income. Interest income increased to $1.0 million for 2006
compared to $0.6 million for 2005. Interest expense decreased to $0.3 million for 2006 compared to
$0.4 million for 2005. Interest expense directly related to equipment is expensed as a cost of the
equipment and is included in the cost of revenue. Other income for 2006 decreased to $0.1 million
compared to $0.3 million for 2005.
Minority Interest in Consolidated Subsidiary. Minority interest in consolidated subsidiary
represents the portion of income, net of tax, attributable to the shares of Ready Mix, Inc. not in
our control. Minority interest for 2006 increased to $1.6 million compared to $0.3 million due to
RMI’s initial public offering in August 2005.
Income Taxes. The increase in the income tax provision for 2006 to $3.2 million compared to
an income tax provision of $2.6 million for 2005 was due to an increase in the pre-tax income
during 2006. For 2006, our effective income tax rate differed from the statutory rate due
primarily to state income taxes. The difference between the amount of the tax provision and the
actual cash outlay was due to the net operating loss carry-forward and the tax treatment of
disqualified dispositions of incentive stock options.
Net Income. Net income remained relatively flat at $4.2 million for 2006 and 2005. Although
net income remained flat, Income Before Income Taxes and Minority Interest in Consolidated
Subsidiary increased to $8.9 million in 2006 compared to $7.1 million in 2005.
Year Ended December 31, 2005 Compared to Year Ended December 31, 2004
Revenue and Backlog. Consolidated revenue improved 10.2% to $183.9 million for the year ended
December 31, 2005, as further referred to as “2005,” from $166.8 million for the year ended
December 31, 2004, as further referred to as “2004.” The improved revenue resulted from an $8.4
million increase, net of inter-company sales, from the CMS, and an increase in revenue from the CSS
of $8.7 million. The CMS revenue increase was due primarily to an approximate 18.1% increase in
the average unit sales price in 2005 from 2004, which was partially offset by a 3.1% decrease in
sales of cubic yards of concrete which we refer to as “units” in 2005 from 2004. Backlog in the
CSS decreased to $68.4 million compared to $93.6 million in 2004. The beginning backlog in the CSS
contributed to the increased revenue in 2005, based on the progress schedules and nature of the
contracts contained in the backlog at the beginning of 2005. Because so much of our business stems
from competitively bid
public works, backlog will fluctuate depending upon the amount and type of contracts that we
bid on and win. Bid bonds provided by our surety company are required on most of the contracts
that we bid, therefore, any restrictions or limitations in the extension of surety credit can
impact the amount and type of contracts available to be bid by our CSS.
Gross Profit. Consolidated gross profit increased to $15.2 million for 2005 from $7.0 million
for 2004 and consolidated gross margin, as a percent of revenue, increased to 8.3% in 2005 from
4.2% in 2004. Gross profit from CSS increased to $8.1 million in 2005 from $0.3 million in 2004
and the gross profit margin increased to 7.0% from 0.3% in the respective periods. In 2005, no
additional loss was required to be recognized on the Gooseberry project. The total anticipated
loss on the project is approximately $7.7 million. In August 2005, we received a notice of
substantial completion from the owner on the Gooseberry project. We have submitted to the owner
the necessary
19
Table of Contents
documentation to support our claims of changed conditions, associated delays and
renegotiable unit prices due to quantity changes and interference. Gross profit margins are
affected by a variety of factors including, the quality and accuracy of the initial estimate,
construction delays and difficulties due to weather or other conditions, availability of materials,
the timing of work performed by other subcontractors and the physical and geological condition of
the construction site. Gross profit from the CMS increased to $7.1 million in 2005 from $6.6
million in 2004 and the gross profit margin decreased to 10.5% from 11.3% in the respective
periods. The increase in gross profit and decrease in the gross profit margin during 2005 resulted
primarily from our expansion of our operation and the under utilizing of new equipment.
Depreciation and Amortization. Depreciation and amortization expense increased to $4.5
million for 2005 from $3.2 million in 2004. The increase resulted from additional plant, equipment
and vehicles we placed in service during 2005 and the 4th quarter of 2004. Of the $4.5
million for 2005, $2.4 million was from our construction materials segment, while $2.1 million came
from our construction services segment.
General and Administrative Expenses. General and administrative expenses increased to $8.7
million for 2005 from $6.5 million for 2004. This increase was primarily attributable to a $1.5
million increase in incentive compensation, a $0.3 million increase in payroll and payroll related
expenses and taxes, increases of $0.1 million in insurance premiums, $0.2 million in legal fees and
increases in public company expenses of $0.3 million, offset by $0.5 million decrease in bad debt
expense.
Interest Income, Expense and Other Income. Interest income increased to $0.5 million for 2005
compared to 2004. Interest expense remained relatively flat at $0.4 million for 2005. Interest
expense directly related to equipment is expensed as a cost of the equipment and is included in the
cost of revenue. Other income for 2005 decreased to $0.3 million compared to 2004. Other income
for 2004 consisted of gains on the disposal of property and equipment, which we did not have
similar transactions in 2005.
Minority Interest in Consolidated Subsidiary. Minority interest in consolidated subsidiary
represents the portion of income, net of tax, attributable to the shares of Ready Mix, Inc. not in
our control.
Income Taxes. The increase in the income tax provision for 2005 to $2.6 million compared to
an income tax provision of $0.3 million for 2004 was due to an increase in the pre-tax income
during 2005. For 2005, our effective income tax rate differed from the statutory rate due
primarily to state income taxes. The difference between the amount of the tax provision and the
actual cash outlay was due to the net operating loss carry-forward and the tax treatment of
disqualified dispositions of incentive stock options.
Net Income. Net income was $4.2 million for 2005 as compared to net income of $0.6 million for
2004. The increase in net income was the result of the improved gross profit, as discussed above,
compared to 2004 where significant losses on the Gooseberry project were recognized.
Liquidity and Capital Resources
Our primary need for capital will be to maximize our working capital to continually improve
our bonding limits (see Bonding and Insurance in Item 1, herein). RMI no longer guarantees any
Meadow Valley debt; however, RMI has indemnified Meadow Valley payment and performance bonds that
were pre-existing prior to September 2005 and the initial public offering of RMI. As of December
31, 2006, Meadow Valley had approximately $0.1
million of payment and performance bonds indemnified by RMI. Certain guarantees also remain where
Meadow Valley Corporation continues to maintain for the benefit of RMI. We expect, but cannot
assure, that eventually there will be no guarantees between the two related companies. As we
expand our businesses we will continue to utilize the availability of capital offered by financial
institutions, in turn increasing our total debt and debt service obligations.
Historically, our primary source of cash has been from operations and financial institutions.
We believe our historical sources of capital will be satisfactory to meet our needs for the coming
year.
During December 2005, we entered into new credit facilities with CIT Construction, which
provides MVCI a $3.0 million revolving credit facility and a $5.0 million capital expenditure
commitment, and RMI a $5.0 million
20
Table of Contents
revolving credit facility as well as a $10.0 million capital
expenditure commitment. The new CIT credit facilities are collateralized by each of our
subsidiary’s assets as well as our guarantee. Under the terms of the agreements, Meadow Valley is
required to maintain a certain level of tangible net worth as well as maintain a ratio of total
debt to tangible net worth, and earnings before interest, tax, depreciation and amortization
(EBITDA). Meadow Valley, MVCI and RMI are also required to maintain a ratio of cash flow to
current portion of long term debt. As of December 31, 2006, we were compliant with the covenants.
The following table sets forth, for the periods presented, certain items from our Statements
of Cash Flows.
| For the Years Ended December 31, | ||||||||||||
| 2006 | 2005 | 2004 | ||||||||||
Cash provided by operating activities |
$ | 10,323,569 | $ | 5,217,432 | $ | 10,986,026 | ||||||
Cash used in investing activities |
(8,002,773 | ) | (5,128,942 | ) | (1,542,131 | ) | ||||||
Cash provided by (used in) financing
activities |
3,468,469 | 13,312,609 | (4,018,065 | ) | ||||||||
Cash provided by operating activities during 2006 of $10.3 million represents a $5.1 million
increase from the amount provided by operating activities during 2005. The change was primarily
due to an increase in the collection of $1.1 million of claims receivable collected in 2006, a net
increase in billings in excess of costs and estimated earnings and a net reduction of costs and
estimated earnings in excess of billings on uncompleted contracts of $3.2 million and the year to
year change in minority interest in consolidated subsidiary, share-based compensation expense and
the allowance for doubtful accounts.
Cash used in investing activities during 2006 of $8.0 million represents a $2.9 million
increase from the amount used in investing activities during 2005. The change was primarily due to
a $3.8 million increase in the purchase of property and equipment, offset by an increase in
proceeds received from payments on note receivable, proceeds received from the sale of property and
equipment and a decrease in restricted cash.
Cash provided by financing activities during 2006 of $3.5 million represents a $9.8 million
decrease from the amount provided by financing activities during 2005. The change was primarily
due to the 2005 net proceeds received from the initial public offering of RMI of $17.1 million,
offset by the increase in proceeds from the issuance of common stock in 2006.
Cash provided by operating activities during 2005 of $5.2 million represents a $5.8 million
decrease from the amount provided by operating activities during 2004. The change was primarily
due to a decrease in the collection of $4.1 million of claims receivable collected in 2004 and an
increase in disbursements in 2005 of $2.2 million in accounts payable when compared to 2004.
Cash used in investing activities during 2005 of $5.1 million represents a $3.6 million
increase from the amount used in investing activities during 2004. The change was primarily due to
a $1.0 million increase in the purchase of property and equipment, a $2.0 million decrease in
proceeds received from the sale of property and equipment and a $0.6 million decrease in restricted
cash.
Cash provided by financing activities during 2005 of $13.3 million represents a $17.3 million
increase from the amount used in financing activities during 2004. The change was primarily due to
a $2.0 million increase in
proceeds from the issuance of common stock, a $17.1 million increase in proceeds from minority
interest in consolidated subsidiary net of offering costs, a $0.4 million decrease in repayment of
capital lease obligations, a $0.7 million decrease in proceeds received from notes payable and a
$1.4 million increase in repayment of notes payable.
Impact of Inflation
There have been increases in the cost of our raw materials and the transport of those
materials, however, we have been able to effectively pass these additional costs on to our
customers. Therefore, we believe that inflation has not had a material impact on our operations.
However, additional substantial increases in labor costs, worker compensation rates and employee
benefits, equipment costs, material or subcontractor costs could adversely affect our operations in
future periods. Furthermore, increased interest rates typically track rising inflation. To the
extent
21
Table of Contents
that rising interest rates equate to higher home mortgage rates, which have an impact on
construction activity, a material rise in the inflation rate could cause a decline in residential
or commercial construction and a negative impact on our business.
Summary of Contractual Obligations and Commercial Commitments
Contractual obligations at December 31, 2006, and the effects such obligations are expected to
have on liquidity and cash flow in future periods, are summarized as follows:
| Payments Due by Period | ||||||||||||||||||||
| Less than | 1 - 3 | 4 - 5 | After | |||||||||||||||||
| (Dollars in thousands) | Total | 1 Year | Years | Years | 5 Years | |||||||||||||||
Contractual Obligations |
||||||||||||||||||||
Long-term debt |
$ | 18,732 | $ | 4,837 | $ | 8,795 | $ | 3,817 | $ | 1,283 | ||||||||||
Interest payments on long-term debt (1) |
3,692 | 1,242 | 1,541 | 461 | 448 | |||||||||||||||
Capital lease obligations |
472 | 366 | 106 | — | — | |||||||||||||||
Operating leases |
10,604 | 3,470 | 5,146 | 1,988 | — | |||||||||||||||
Purchase obligations |
27,580 | 3,720 | 7,181 | 5,188 | 11,491 | |||||||||||||||
Other long term liabilities (2) |
2,755 | 1,347 | 1,408 | — | — | |||||||||||||||
Total contractual obligations |
$ | 63,835 | $ | 14,982 | $ | 24,177 | $ | 11,454 | $ | 13,222 | ||||||||||
| (1) | Interest payments are based on the individual interest rates of each obligation, which range from 1.90% to 9.75% per annum. We do not assume an increase in the variable interest rate. See Note 10 – Notes payable and Note 11 – Lines of Credit in the notes to the consolidated financial statements included in Item 8. | |
| (2) | Other long-term liabilities include employment contracts with officers and key employees that call for annual salaries ranging from $115,000 to $250,000 through October 2009, and are to be reviewed annually by our Compensation Committee. |
Known and Anticipated Future Trends and Contingencies
Our CMS has shown steady growth since its inception and we plan to continue to exploit
opportunities within that segment of our business. The initial public offering completed in 2005
for a portion of RMI was to raise capital for such purposes. The key dynamics of employment and
population growth within our geographic markets appear to present the CMS with continued growth
opportunities. It appears that demand for construction materials will remain steady and that the
supply of raw materials will remain relatively limited, thereby likely maintaining stable prices,
or, if costs rise, a possibility of further price increases.
We have exited the construction services market in New Mexico and Utah, however, we may
occasionally perform work in southern Utah that we believe can be effectively managed from our full
time office in Las Vegas and we still maintain a small sand and gravel operation in Nephi, Utah.
In spite of having physically exited these markets, we continue to expend resources dealing with
two New Mexico projects with unresolved claims and we have finalized a claim that we submitted to
the Federal Highway Administration on the Gooseberry project that was completed in 2005. We
believe we have conservatively booked claim revenue on the New Mexico projects and the Gooseberry
project. Therefore, in the future, we believe we may be able to recover at least what we have
booked to date, if not more.
If the CSS can continue to demonstrate operating improvements, then as profitability, working
capital and liquidity increase, our surety credit will likely increase, thereby allowing us to bid
on and perform more and larger projects. Bidding opportunities within our focused market areas of
Nevada and Arizona are ample for the size of our current surety program and we believe, given
historical bidding success, that the backlog may increase during 2007.
22
Table of Contents
As public works constitute the majority of our CSS volume, and governmental entities are the
primary source of funding for infrastructure work, it is, therefore, important that public funding
be maintained. The national transportation legislation, SAFETEA-LU, was signed by President Bush
on August 10, 2005 and should provide relatively stable funding for transportation infrastructure
at least until its expiration in the fall of 2009.
The competitive bidding process will continue to be the dominant method for determining
contract awards. However, other innovative bidding methods will be tried and may gain favor,
namely “A Plus B” contracts, where the bidders’ proposals are selected on both price and scheduling
criteria. Design-build projects and Construction Manager at Risk projects are becoming more common
and are likely to increase in frequency. We recently won our first design-build project. The
contract is valued at approximately $.5 million, but we believe it represents a low risk
opportunity to enter this venue of work.
In light of the rising need for infrastructure work throughout the nation and the tendency of
the current need to out-pace the supply of funds, it is anticipated that alternative funding
sources will continue to be sought. Funding for infrastructure development in the United States is
coming from a growing variety of innovative sources. An increase of funding measures is being
undertaken by various levels of government to help solve traffic congestion and related air quality
problems. Sales taxes, fuel taxes, user fees in a variety of forms, vehicle license taxes, private
toll roads and quasi-public toll roads are examples of how transportation funding is evolving.
Transportation norms are being challenged by federally mandated air quality standards. Improving
traffic movement, eliminating congestion, increasing public transit, adding or designating high
occupancy vehicle (HOV) lanes to encourage car pooling and other solutions are being considered in
order to help meet EPA-imposed air quality standards. There is also a trend toward local and state
legislation regulating growth and urban sprawl. The passage of such legislation and the degree of
growth limits imposed by it could dramatically affect the nature of our markets.
In November 2004, voters in Maricopa County (Phoenix, Arizona metropolitan area) passed a
measure to extend, for twenty years, a half-cent sales tax dedicated to the construction and
maintenance of transportation facilities, including freeways, streets and mass transit. It is
expected that this measure will generate approximately $9.0 billion of funding over a twenty year
span.
Critical Accounting Policies
Management’s Discussion and Analysis of Financial Condition and Results of Operations is based
upon our financial statements, which have been prepared in accordance with accounting policies
generally accepted in the United States of America, or “GAAP.” We base our estimates on historical
experience and on various other assumptions that are believed to be reasonable under the
circumstances, the results of which form the basis for making judgments about the carrying values
of assets and liabilities that are not readily apparent from other sources. Actual results may
materially differ from these estimates under different assumptions or conditions.
Our significant accounting policies are described below and in Note 1 to the consolidated
financial statements included in Item 8 of this Form 10-K. We believe our most critical accounting
policies are the revenue recognition and cost estimation on certain contracts for which we use a
percentage-of-completion accounting
method, our allowance for doubtful accounts and the allowance for slow moving and obsolete
inventory. The revenue recognition and cost estimation accounting method is applied by the CSS to
heavy construction projects executed under multi-year contracts with various customers.
Approximately 57%, 64% and 65% of total net revenue was recognized under the
percentage-of-completion method of accounting during 2006, 2005 and 2004, respectively.
Revenue and Cost Recognition:
Revenues and costs from fixed-price and modified fixed-price construction contracts are
recognized for each contract on the percentage-of-completion method, measured by the percentage of
costs incurred to-date to the estimated total of direct costs. Direct costs include, among other
things, direct labor, field labor, equipment rent, subcontracting, direct materials, and direct
overhead. General and administrative expenses are accounted for as period costs and are,
therefore, not included in the calculation of the estimates to complete construction contracts in
progress. Project losses are provided for in their entirety in the period in which such losses are
determined, without reference to the percentage-of-completion. As contracts can extend over one or
more accounting periods, revisions
23
Table of Contents
in costs and earnings estimated during the course of the work
are reflected during the accounting period in which the facts that required such revisions become
known.
The asset “costs and estimated earnings in excess of billings on uncompleted contracts”
represents revenue recognized in excess of amounts billed. The liability “billings in excess of
costs and estimated earnings on uncompleted contracts” represents billings in excess of revenue
recognized.
The complexity of the estimation process and all issues related to the assumptions, risks and
uncertainties inherent with the application of the percentage-of-completion method of accounting
affects the amounts reported in our consolidated financial statements. A number of internal and
external factors affect our percentage-of-completion estimates, including labor rate and efficiency
variances, estimated future material prices and customer specification changes. If our business
conditions were different, or if we used different assumptions in the application of this
accounting policy, it is likely that materially different amounts would be reported in our
consolidated financial statements.
Collectibility of Accounts Receivable
We are also required to estimate the collectibility of our accounts receivable. A
considerable amount of judgment is required in assessing the realization of these receivables,
including the current credit worthiness of each customer and the related aging of the past due
balances. Our provision for bad debts as of December 31, 2006 and 2005 amounted to $395,243 and
$326,112, respectively. We determine our reserve by using percentages applied to certain aged
receivable categories and percentages of certain types of revenue generated, as well as a review of
the individual accounts outstanding and our collection history.
Inventory, net:
We are required to state our inventories at the lower of cost or market. In assessing the
ultimate realization of inventories, we are required to make judgments as to the future demand
requirements and compare these with the current inventory levels. Our reserve requirements
generally increase as our projected demand requirements decrease due to market conditions and
longer than expected usage periods. At December 31, 2006 and 2005, inventories of $1,366,534 and
$776,978, respectively, are net of reserves of $200,000 and $244,271, respectively. It is possible
that significant changes in required inventory reserves may continue to occur in the future if
there is a further decline in market conditions or market activity.
Valuation of Property and Equipment:
We are required to provide property and equipment net of depreciation and amortization
expense. We expense depreciation and amortization utilizing the straight-line method, over what we
believe to be the estimated useful lives. Leasehold improvements are amortized over their
estimated useful lives or the lease term, whichever is shorter. The estimated useful lives of
property and equipment are:
Plants |
4 - 15 years | |
Computer equipment |
3 - 5 years | |
Equipment |
3 - 10 years | |
Leasehold improvements |
2 - 10 years | |
Office furniture and equipment |
5 - 7 years | |
Vehicles |
3 - 10 years | |
Office Building |
39 years |
The life on any piece of equipment can vary, even within the same category of equipment, due
to the quality of the maintenance, care provided by the operator and the general environmental
conditions, such as temperature, rain and the terrain conditions to reach the job site where the
material is delivered. We maintain, service and repair approximately 95% of our equipment through
the use of our mechanics. If we inaccurately estimate the life of any given piece of equipment or
category of equipment we may be overstating or understating earnings in any given period.
We also review our property and equipment for impairment whenever events or changes in
circumstances indicate that the carrying amount of an asset may not be recoverable. Recoverability
of assets to be held and used is
24
Table of Contents
measured by a comparison of the carrying amount of an asset to
future net cash flows expected to be generated by the asset. If such assets are considered to be
impaired, the impairment recognized is measured by the amount by which the carrying amount of the
assets exceeds the fair value of the assets. The impairments are recognized in the period during
which they are identified. Assets to be disposed of are reported at the lower of the carrying
amount or fair value less costs to sell.
Income taxes:
We are required to estimate our income taxes in each jurisdiction in which we operate. This
process requires us to estimate the actual current tax exposure together with assessing temporary
differences resulting from differing treatment of items for tax and financial reporting purposes.
These temporary differences result in deferred tax assets and liabilities on our consolidated
balance sheets. We must calculate the blended tax rate, combining all applicable tax
jurisdictions, which can vary over time as a result of the allocation of taxable income between the
tax jurisdictions and the changes in tax rates. We must also assess the likelihood that the
deferred tax assets, if any, will be recovered from future taxable income and, to the extent
recovery is not likely, must establish a valuation allowance. This assessment is complicated by the
fact that we are required to consolidate our subsidiaries for financial reporting purposes, while
being separately reported for tax purposes.
Furthermore, we are subject to periodic review by domestic tax authorities for audit of our
income tax returns. These audits generally include questions regarding our tax filing positions,
including the amount and timing of deductions and the allocation of income among various tax
jurisdictions. In evaluating the exposures associated with our various tax filing positions,
including federal and state taxes, we believe we have complied with the rules of the service codes
and therefore have not recorded reserves for any possible exposure. Typically the taxing
authorities can audit the previous three years of tax returns and in certain situations audit
additional years, therefore a significant amount of time may pass before an audit is conducted and
fully resolved. Although no audits are currently being conducted, if a taxing authority would
require us to amend a prior year’s tax return we would record the increase or decrease in our tax
obligation in the year in which it is more likely than not to be realized.
Classification of Leases:
We follow the standards established by Statements of Financial Accounting Standards No. 13,
“Accounting for Leases,” which we will refer to as “FAS 13.” One factor when determining if a lease
is an operating lease or a capital lease is the intention from the inception of the lease regarding
the final ownership, or transfer of title, of the asset to be leased. We are currently leasing 92
ready-mix trucks under operating lease agreements, since at the inception of those leases we had
not intended to take title to those vehicles at the conclusion of the leases. Therefore, we did not
request transfer of ownership provisions at the conclusion of the leases such as bargain purchase
options or direct transfers of ownership. Since we do not intend to take ownership at the
conclusion of the leases and we do not meet the remaining criteria of FAS 13 for capitalization,
the leases are classified as operating leases. If we would have desired at the inception of the
leases to have the ownership transfer at the conclusion of the leases, we would have classified
those leases as capital leases and would have recorded the ready-mix trucks as assets on our
balance sheet as well as recording the liability as capital lease obligations. We believe that the
lease expense under the
operating lease classification approximates the depreciation expense which would have been incurred
if the leases would have been classified as capital leases.
Recent Accounting Pronouncements
In September 2006, the SEC issued SAB No. 108, “Considering the Effects of Prior Year
Misstatements when Quantifying Misstatements in Current Year Financial Statements,” to address
diversity in practice in quantifying financial statement misstatements. SAB No. 108 requires that
we quantify misstatements based on their impact on each of our financial statements and related
disclosures. SAB No. 108 is effective as of the end of the 2006 fiscal year, allowing a one-time
transitional cumulative effect adjustment to retained earnings as of January 1, 2006 for errors
that were not previously deemed material, but are material under the guidance in SAB No. 108. The
adoption of SAB No. 108 did not have a material effect on our financial statements.
In September 2006, the FASB issued SFAS No. 158, “Employer’s Accounting for Defined Benefit
Pension and Other Postretirement Plans – an amendment of FASB Statements No. 87, 88, 106, and
132(R).” SFAS No. 158 requires the recognition of the overfunded or underfunded status of defined
benefit and retiree medical plans as an asset or liability in the Company’s 2006 year-end balance
sheet, with changes in the funded status recognized
25
Table of Contents
through comprehensive income in the year in
which they occur. SFAS No. 158 also requires us to measure the funded status of defined benefit
and retiree medical plans as of our year-end balance sheet date no later than 2008. We do not
expect SFAS No. 158 will have a material effect on our financial statements.
In September 2006, the FASB issued SFAS No. 157, “Fair Value Measurements,” which defines fair
value, establishes a framework for measuring fair value, and expands disclosures about fair value
measurements. SFAS No. 157 is effective for fiscal years beginning after November 15, 2007. We do
not expect SFAS No. 157 will have a material effect on our financial statements.
In June 2006, the FASB issued FASB Interpretation No. 48, “An Interpretation of FASB Statement
No. 109,” which clarifies the accounting for uncertainty in income taxes recognized in a company’s
financial statements in accordance with FASB Statement No. 109, “Accounting for Income Taxes.”
This Interpretation prescribes a recognition threshold and measurement attribute for the financial
statement recognition and measurement of a tax position taken or expected to be taken in a tax
return. FIN No. 48 reflects the benefit recognition approach, where a tax benefit is recognized
when it is “more likely than not” to be sustained based on the technical merits of the position.
This Interpretation is effective for fiscal years beginning after December 15, 2006. We do not
expect FIN No. 48 will have a material effect on our financial statements.
In April 2006, the FASB issued FASB Staff Position (FSP) FIN No. 46(R)-6, “Determining the
Variability to Be Considered in Applying FASB Interpretation No. 46(R),” that became effective
beginning the third quarter of 2006. FSP FIN No. 46(R)-6 clarifies that the variability to be
considered in applying FASB Interpretation 46(R) shall be based on an analysis of the design of the
variable interest entity. The adoption of this FSP did not have a material effect on our financial
statements.
In March 2006, the FASB issued SFAS No. 156, “Accounting for Servicing of Financial Assets,”
which provides an approach to simplify efforts to obtain hedge-like (offset) accounting. This new
Statement amends SFAS No. 140, “Accounting for Transfers and Servicing of Financial Assets and
Extinguishments of Liabilities,” with respect to the accounting for separately recognized servicing
assets and servicing liabilities. SFAS No. 156 is effective for all separately recognized
servicing assets and liabilities as of the beginning of an entity’s fiscal year that begins after
September 15, 2006, with earlier adoption permitted in certain circumstances. We do not expect
SFAS No. 156 will have a material effect on our financial statements.
The FASB has revised its guidance on SFAS No. 133 Implementation Issues as of March 2006.
Several Implementation Issues were revised to reflect the issuance of SFAS No. 155, “Accounting for
Certain Hybrid Financial Instruments – an Amendment of FASB Statements No. 133 and 140,” in
February 2006. SFAS No. 155 allows any hybrid financial instrument that contains an embedded
derivative that otherwise would require bifurcation under SFAS No. 133, “Accounting for Derivative
Instruments and Hedging Activities” to be carried at fair value in its entirety, with changes in
fair value recognized in earnings. In addition, SFAS No. 155 requires that beneficial interests in
securitized financial assets be analyzed to determine whether they are freestanding derivatives
or contain an embedded derivative. SFAS No. 155 also eliminates a prior restriction on the
types of passive derivatives that a qualifying special purpose entity is permitted to hold. SFAS
No. 155 is applicable to new or modified financial instruments in fiscal years beginning after
September 15, 2006, though the provisions related to fair value accounting for hybrid financial
instruments can also be applied to existing instruments. We do not expect SFAS No. 155 will have a
material effect on our financial statements.
Off-Balance Sheet Arrangements
We had no off-balance sheet arrangements that have or are reasonably likely to have a current
or future effect on our financial condition, changes in our financial condition, revenues or
expenses, results of operations, liquidity, capital expenditures or capital resources that is
material to investors.
26
Table of Contents
Item 7A. Quantitative and Qualitative Disclosures About Market Risk
Market risk generally represents the risk that losses may occur in the values of financial
instruments as a result of movements in interest rates, foreign currency exchange rates and
commodity prices. We do not have foreign currency exchange rate and commodity price market risk.
Interest Rate Risk – From time to time we temporarily invest our excess cash and restricted
cash in interest-bearing securities issued by high-quality issuers. We monitor risk exposure to
monies invested in securities in our financial institutions. Due to the short time the investments
are outstanding and their general liquidity, these instruments are classified as cash equivalents
in our consolidated balance sheets and do not represent a material interest rate risk. Our primary
market risk exposure for changes in interest rates relates to our long-term debt obligations. We
manage our exposure to changing interest rates principally through the use of a combination of
fixed and floating rate debt.
We evaluated the potential effect that near term changes in interest rates would have had on
the fair value of our interest rate risk sensitive financial instruments at December 31, 2006.
Assuming a 100 basis point increase in the prime interest rate at December 31, 2006 the potential
increase in our debt obligations would have been approximately $0.03 million at December 31, 2006.
See Note 10 — Notes payable and Note 11 — Lines of credit in the accompanying consolidated
financial statements included in Item 8.
27
Table of Contents
Item 8. Financial Statements and Supplementary Data
 |
||
Report of Independent Registered Public Accounting Firm
Board of Directors and Stockholders of
Meadow Valley Corporation
Meadow Valley Corporation
We have audited the accompanying consolidated balance sheets of Meadow Valley
Corporation and Subsidiaries as of December 31, 2006 and 2005 and the related
consolidated statements of income, stockholders’ equity, and cash flows for the
years ended December 31, 2006, 2005 and 2004. These consolidated financial
statements are the responsibility of the Company’s management. Our responsibility
is to express an opinion on these financial statements based on our audits.
We conducted our audits in accordance with standards of the Public Company
Accounting Oversight Board (United States). Those standards require that we plan
and perform the audit to obtain reasonable assurance about whether the financial
statements are free of material misstatement. An audit includes consideration of
internal control over financial reporting as a basis for designing audit
procedures that are appropriate in the circumstances, but not for the purpose of
expressing an opinion on the effectiveness of the Company’s internal control over
financial reporting. Accordingly, we express no such opinion. An audit also
includes examining, on a test basis, evidence supporting the amounts and
disclosures in the financial statements, assessing the accounting principles used
and significant estimates made by management, as well as evaluating the overall
financial statement presentation. We believe that our audits provide a reasonable
basis for our opinion.
In our opinion, the consolidated financial statements referred to above present
fairly, in all material respects, the consolidated financial position of Meadow
Valley Corporation and Subsidiaries at December 31, 2006 and 2005, and the
results of its operations and its cash flows for the years ended December 31,
2006, 2005 and 2004 in conformity with accounting principles generally accepted
in the United States of America.
Certified Public Accountants
Phoenix, Arizona
March 2, 2007
March 2, 2007
INDEPENDENT MEMBER OF THE BDO SEIDMAN ALLIANCE
28
Table of Contents
MEADOW VALLEY CORPORATION AND SUBSIDIARIES
CONSOLIDATED BALANCE SHEETS
CONSOLIDATED BALANCE SHEETS
| December 31, | ||||||||
| 2006 | 2005 | |||||||
Assets: |
||||||||
Current assets: |
||||||||
Cash and cash equivalents |
$ | 29,354,582 | $ | 23,565,317 | ||||
Restricted cash |
605,243 | 1,267,090 | ||||||
Accounts receivable, net |
25,990,763 | 25,139,640 | ||||||
Prepaid expenses and other |
2,820,768 | 3,171,670 | ||||||
Inventory, net |
1,366,534 | 776,978 | ||||||
Costs and estimated earnings in excess of billings on uncompleted
contracts |
1,254,860 | 1,991,993 | ||||||
Note receivable |
106,499 | — | ||||||
Deferred tax asset |
561,199 | 760,724 | ||||||
Total current assets |
62,060,448 | 56,673,412 | ||||||
Property and equipment, net |
35,553,000 | 26,228,073 | ||||||
Refundable deposits |
1,492,967 | 478,965 | ||||||
Note receivable, less current portion |
535,360 | — | ||||||
Claims receivable |
2,463,880 | 3,521,080 | ||||||
Other receivables |
— | 115,000 | ||||||
Total assets |
$ | 102,105,655 | $ | 87,016,530 | ||||
Liabilities and Stockholders’ Equity: |
||||||||
Current liabilities: |
||||||||
Accounts payable |
$ | 13,298,114 | $ | 18,521,558 | ||||
Accrued liabilities |
7,569,928 | 5,878,595 | ||||||
Notes payable |
4,837,628 | 3,518,892 | ||||||
Obligations under capital leases |
332,898 | 546,801 | ||||||
Income tax payable |
399,536 | 391,202 | ||||||
Billings in excess of costs and estimated earnings on uncompleted
contracts |
8,366,754 | 5,903,087 | ||||||
Total current liabilities |
34,804,858 | 34,760,135 | ||||||
Notes payable, less current portion |
13,894,382 | 11,423,044 | ||||||
Obligations under capital leases, less current portion |
102,100 | 434,998 | ||||||
Deferred tax liability |
2,974,857 | 3,177,771 | ||||||
Total liabilities |
51,776,197 | 49,795,948 | ||||||
Commitments and contingencies
|
||||||||
Minority interest in consolidated subsidiary |
18,988,244 | 17,424,795 | ||||||
Stockholders’ equity: |
||||||||
Preferred stock — $.001 par value; 1,000,000 shares authorized, none
issued and outstanding |
— | — | ||||||
Common stock — $.001 par value; 15,000,000 shares authorized,
5,098,679 and 4,136,912 issued and outstanding |
5,099 | 4,137 | ||||||
Additional paid-in capital |
21,197,456 | 13,818,913 | ||||||
Capital adjustments |
(799,147 | ) | (799,147 | ) | ||||
Retained earnings |
10,937,806 | 6,771,884 | ||||||
Total stockholders’ equity |
31,341,214 | 19,795,787 | ||||||
Total liabilities and stockholders’ equity |
$ | 102,105,655 | $ | 87,016,530 | ||||
The accompanying notes are an integral part of these consolidated financial statements.
29
Table of Contents
MEADOW VALLEY CORPORATION AND SUBSIDIARIES
CONSOLIDATED STATEMENTS OF OPERATIONS
CONSOLIDATED STATEMENTS OF OPERATIONS
| For the Years Ended December 31, | ||||||||||||
| 2006 | 2005 | 2004 | ||||||||||
Revenue: |
||||||||||||
Construction services |
$ | 111,936,285 | $ | 116,822,072 | $ | 108,168,921 | ||||||
Construction materials |
83,151,938 | 67,050,791 | 58,662,743 | |||||||||
Construction materials testing |
433,728 | — | — | |||||||||
Total revenue |
195,521,951 | 183,872,863 | 166,831,664 | |||||||||
Cost of revenue: |
||||||||||||
Construction services |
101,866,540 | 108,706,174 | 107,827,853 | |||||||||
Construction materials |
73,945,571 | 59,979,110 | 52,036,021 | |||||||||
Construction materials testing |
399,752 | — | — | |||||||||
Total cost of revenue |
176,211,863 | 168,685,284 | 159,863,874 | |||||||||
Gross profit |
19,310,088 | 15,187,579 | 6,967,790 | |||||||||
General and administrative expenses |
11,161,819 | 8,666,573 | 6,509,839 | |||||||||
Income from operations |
8,148,269 | 6,521,006 | 457,951 | |||||||||
Other income (expense): |
||||||||||||
Interest income |
1,010,144 | 562,914 | 85,864 | |||||||||
Interest expense |
(338,886 | ) | (362,326 | ) | (348,229 | ) | ||||||
Other income |
73,629 | 341,603 | 694,857 | |||||||||
| 744,887 | 542,191 | 432,492 | ||||||||||
Income before income taxes and minority
interest in consolidated subsidiary |
8,893,156 | 7,063,197 | 890,443 | |||||||||
Income tax expense |
3,163,785 | 2,570,955 | 316,804 | |||||||||
Income before minority interest
in consolidated subsidiary |
5,729,371 | 4,492,242 | 573,639 | |||||||||
Minority interest in consolidated subsidiary |
1,563,449 | 288,523 | — | |||||||||
Net income |
$ | 4,165,922 | $ | 4,203,719 | $ | 573,639 | ||||||
Basic net income per common share |
$ | 0.96 | $ | 1.11 | $ | 0.16 | ||||||
Diluted net income per common share |
$ | 0.90 | $ | 1.01 | $ | 0.15 | ||||||
Basic weighted average common shares outstanding |
4,328,160 | 3,783,089 | 3,601,250 | |||||||||
Diluted weighted average common shares outstanding |
4,621,124 | 4,151,096 | 3,780,597 | |||||||||
The accompanying notes are an integral part of these consolidated financial statements.
30
Table of Contents
MEADOW VALLEY CORPORATION AND SUBSIDIARIES
CONSOLIDATED STATEMENTS OF CHANGES IN STOCKHOLDERS’ EQUITY
CONSOLIDATED STATEMENTS OF CHANGES IN STOCKHOLDERS’ EQUITY
| Common Stock | ||||||||||||||||||||
| Number of | Additional | |||||||||||||||||||
| Shares | Paid-in | Capital | Retained | |||||||||||||||||
| Outstanding | Amount | Capital | Adjustment | Earnings | ||||||||||||||||
Balance at January 1, 2004 |
3,601,250 | $ | 3,601 | $ | 10,943,569 | $ | (799,147 | ) | $ | 1,994,526 | ||||||||||
Net income for the year ended 2004 |
— | — | — | — | 573,639 | |||||||||||||||
Balance at December 31, 2004 |
3,601,250 | 3,601 | 10,943,569 | (799,147 | ) | 2,568,165 | ||||||||||||||
Common stock issued on exercise
of options, net of tax benefit(1) |
535,662 | 536 | 2,875,344 | — | — | |||||||||||||||
Net income for the year ended 2005 |
— | — | — | — | 4,203,719 | |||||||||||||||
Balance at December 31, 2005 |
4,136,912 | 4,137 | 13,818,913 | (799,147 | ) | 6,771,884 | ||||||||||||||
Common stock issued in
private placement offering |
817,120 | 817 | 6,567,083 | — | — | |||||||||||||||
Stock-based compensation expense |
— | — | 267,110 | — | — | |||||||||||||||
Excess tax benefits from stock-based
payment arrangements |
— | — | 144,879 | — | — | |||||||||||||||
Common stock issued on exercise
of options |
144,647 | 145 | 399,471 | — | — | |||||||||||||||
Net income for the year ended 2006 |
— | — | — | — | 4,165,922 | |||||||||||||||
Balance at December 31, 2006 |
5,098,679 | $ | 5,099 | $ | 21,197,456 | $ | (799,147 | ) | $ | 10,937,806 | ||||||||||
| (1) | – Additional paid-in capital associated with the issuance of common stock on exercise of options for 2005 includes an income tax benefit of $884,083. |
The accompanying notes are an integral part of these consolidated financial statements.
31
Table of Contents
MEADOW VALLEY CORPORATION AND SUBSIDIARIES
CONSOLIDATED STATEMENTS OF CASH FLOWS
CONSOLIDATED STATEMENTS OF CASH FLOWS
| For the Years Ended December 31, | ||||||||||||
| 2006 | 2005 | 2004 | ||||||||||
Increase (decrease) in cash and cash equivalents: |
||||||||||||
Cash flows from operating activities: |
||||||||||||
Cash received from customers |
$ | 198,871,293 | $ | 178,671,433 | $ | 173,023,546 | ||||||
Cash paid to suppliers and employees |
(186,080,171 | ) | (173,653,659 | ) | (161,769,236 | ) | ||||||
Interest received |
1,010,144 | 562,914 | 85,864 | |||||||||
Interest paid |
(338,886 | ) | (362,326 | ) | (348,229 | ) | ||||||
Income taxes paid |
(3,138,811 | ) | (930 | ) | (5,919 | ) | ||||||
Net cash provided by operating activities |
10,323,569 | 5,217,432 | 10,986,026 | |||||||||
Cash flows from investing activities: |
||||||||||||
Decrease in restricted cash |
661,847 | 1,359 | 576,442 | |||||||||
Proceeds from sale of property and equipment |
552,270 | 391,504 | 2,450,931 | |||||||||
Purchase of property and equipment |
(9,368,571 | ) | (5,521,805 | ) | (4,569,504 | ) | ||||||
Proceeds from note receivable |
151,681 | — | — | |||||||||
Net cash used in investing activities |
(8,002,773 | ) | (5,128,942 | ) | (1,542,131 | ) | ||||||
Cash flows from financing activities: |
||||||||||||
Proceeds from the issuance of common stock |
7,753,696 | 1,991,797 | — | |||||||||
Offering costs associated with private placement offering |
(786,180 | ) | — | — | ||||||||
Proceeds from minority interest in consolidated subsidiary |
— | 17,747,900 | — | |||||||||
Offering costs associated with minority interest
in consolidated subsidiary |
— | (611,628 | ) | — | ||||||||
Repayment of capital lease obligations |
(546,801 | ) | (531,746 | ) | (906,191 | ) | ||||||
Proceeds received from notes payable |
3,083,540 | 543,998 | 1,281,570 | |||||||||
Repayment of notes payable |
(6,180,665 | ) | (5,827,712 | ) | (4,393,444 | ) | ||||||
Excess tax benefits from share-based payment arrangements |
144,879 | — | — | |||||||||
Net cash provided by (used in) financing activities |
3,468,469 | 13,312,609 | (4,018,065 | ) | ||||||||
Net increase in cash and cash equivalents |
5,789,265 | 13,401,099 | 5,425,830 | |||||||||
Cash and cash equivalents at beginning of year |
23,565,317 | 10,164,218 | 4,738,388 | |||||||||
Cash and cash equivalents at end of year |
$ | 29,354,582 | $ | 23,565,317 | $ | 10,164,218 | ||||||
The accompanying notes are an integral part of these consolidated financial statements.
32
Table of Contents
MEADOW VALLEY CORPORATION AND SUBSIDIARIES
CONSOLIDATED STATEMENTS OF CASH FLOWS (Continued)
CONSOLIDATED STATEMENTS OF CASH FLOWS (Continued)
| For the Years Ended December 31, | ||||||||||||
| 2006 | 2005 | 2004 | ||||||||||
Increase (decrease) in cash and cash equivalents (Continued): |
||||||||||||
Reconciliation of net income to net cash
provided by operating activities: |
||||||||||||
Net income |
$ | 4,165,922 | $ | 4,203,719 | $ | 573,639 | ||||||
Adjustments to reconcile net income to net
cash provided by operating activities: |
||||||||||||
Depreciation and amortization |
5,885,481 | 4,499,044 | 3,201,683 | |||||||||
Gain on sale of property and equipment |
(42,002 | ) | (9,397 | ) | (485,911 | ) | ||||||
Share-based compensation expense |
267,110 | — | — | |||||||||
Deferred taxes, net |
(3,389 | ) | 2,198,853 | 310,885 | ||||||||
Allowance for doubtful accounts |
69,131 | (281,565 | ) | (102,476 | ) | |||||||
Inventory allowance |
(44,271 | ) | (42,551 | ) | (917,375 | ) | ||||||
Minority interest in consolidated
subsidiary |
1,563,449 | 288,523 | — | |||||||||
Changes in operating assets and liabilities: |
||||||||||||
Accounts receivable |
(940,284 | ) | (2,674,326 | ) | (1,397,221 | ) | ||||||
Income taxes receivable |
20,030 | (20,030 | ) | — | ||||||||
Claims receivable |
1,057,200 | — | 4,101,898 | |||||||||
Prepaid expenses and other |
92,456 | 62,742 | (238,707 | ) | ||||||||
Inventory |
(545,285 | ) | 136,685 | 1,295,381 | ||||||||
Costs and estimated earnings in excess of billings on
uncompleted contracts |
737,133 | (1,542,635 | ) | 1,013,951 | ||||||||
Refundable deposits |
(1,014,002 | ) | (457,185 | ) | 72,519 | |||||||
Other receivables |
115,000 | — | (115,000 | ) | ||||||||
Accounts payable |
(5,223,444 | ) | (1,190,013 | ) | 1,064,714 | |||||||
Accrued liabilities |
1,691,333 | 971,041 | 343,738 | |||||||||
Income taxes payable |
8,334 | 391,202 | — | |||||||||
Billings in excess of costs and estimated earnings on
uncompleted contracts |
2,463,667 | (1,316,675 | ) | 2,264,308 | ||||||||
Net cash provided by operating activities |
$ | 10,323,569 | $ | 5,217,432 | $ | 10,986,026 | ||||||
The accompanying notes are an integral part of these consolidated financial statements.
33
Table of Contents
MEADOW VALLEY CORPORATION AND SUBSIDIARIES
NOTES TO CONSOLIDATED FINANCIAL STATEMENTS
NOTES TO CONSOLIDATED FINANCIAL STATEMENTS
1. Summary of Significant Accounting Policies and Use of Estimates:
Nature of the Corporation:
Meadow Valley Corporation (the “Company”) was organized under the laws of the State of Nevada
on September 15, 1994. The principal business purpose of the Company is to operate as the holding
company of Meadow Valley Contractors, Inc. (“MVCI”) (“Construction services segment”), Ready Mix,
Inc. (“RMI”) (“Construction materials segment”) and Apex Testing Corp. (“Apex”) (“Construction
materials testing segment”). MVCI is a general contractor, primarily engaged in the construction
of structural concrete highway bridges and overpasses, and the paving of highways and airport
runways for various governmental authorities, municipalities and developers in the states of
Nevada, Arizona and southern Utah. RMI manufactures and distributes ready mix concrete in the Las
Vegas, NV and Phoenix, AZ metropolitan areas. In 2005, the Company sold, in a public offering,
approximately 47% of its ownership interest in RMI and continues to own approximately 53% of RMI’s
outstanding common stock. Apex is a construction materials testing provider in the Las Vegas,
Nevada area. In May 2006, Apex was formed and subsequently, assets were purchased for
approximately $134,000 from an existing materials testing company in Las Vegas, Nevada.
Liquidity:
The Company incurred income from operations for the years ended December 31, 2006, 2005 and
2004 of $8,148,269, $6,521,006 and $457,951 and has provided cash from operating activities of
$10,323,569, $5,217,432 and $10,986,026 for the years ended December 31, 2006, 2005 and 2004. In
2004, the Company sold a parcel of land, held by the construction service segment, to a third party
for $350,000 resulting in a gain on the disposal of the land in the amount of $44,668, which is
included in other income. In 2005 the Company sold approximately 47% of its stake in a subsidiary,
RMI, through an initial public offering, which resulted in approximately $17.1 million in net
proceeds after underwriters’ commissions and other offering costs. The Company continues to own
approximately 53% of the outstanding shares of RMI as of December 31, 2006. In 2006 the Company
sold 817,120 shares of common stock par value $0.001 in a private placement offering, which
resulted in approximately $6.6 million in net proceeds after underwriting commissions and other
costs.
In January 2004, the Company agreed to accept $7,000,000, including retention of $1,127,636,
in exchange for releasing the New Mexico State Highway and Transportation Department (“NMSHTD”)
from three of the five claims which had been filed against the NMSHTD. The claim amount of the
three settled claims totaled $15,463,207, of which $15,366,128 was on behalf of the Company and the
balance of $97,079 was on behalf of subcontractors. The Company previously recorded a claim
receivable in the amount of $4,101,898 related to the three claims. The Company recognized
$1,770,466 in additional income, included in construction services segment revenue, for the year
ended December 31, 2004, as a result of the $7,000,000 settlement from the New Mexico State Highway
and Transportation Department.
Principles of Consolidation:
The accompanying consolidated financial statements include the accounts of the Company and its
subsidiaries MVCI, RMI and Apex. Intercompany transactions and balances have been eliminated in
consolidation.
Reclassifications:
Certain balances in the accompanying December 31, 2005 consolidated balance sheet were
reclassified to conform to the current year’s presentation.
Accounting Estimates:
The preparation of financial statements in conformity with accounting principles generally
accepted in the United States of America requires management to make estimates and assumptions that
affect the reported amounts of assets and liabilities and disclosure of contingent assets and
liabilities at the date of the financial statements and the reported amounts of revenue and
expenses during the reporting period. Actual results could differ materially from those estimates.
Significant estimates are used when accounting for the percentage-of-completion and the
estimated gross profit on projects in progress, allowance for doubtful accounts, inventory
allowance, depreciation and amortization,
realization of claims receivable, accruals, taxes, contingencies and the valuation of
stock-based compensation instruments which are discussed in the respective notes to the
consolidated financial statements.
34
Table of Contents
MEADOW VALLEY CORPORATION AND SUBSIDIARIES
NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)
NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)
1. Summary of Significant Accounting Policies and Use of Estimates (Continued):
Revenue and Cost Recognition:
Revenue and costs from fixed-price and modified fixed-price construction contracts are
recognized for each contract on the percentage-of-completion method, measured by the percentage of
costs incurred to date to the estimated total of direct costs. Direct costs include, among other
things, direct labor, field labor, equipment rent, subcontracting, direct materials, and direct
overhead. General and administrative expenses are accounted for as
period costs and are, therefore, not included in the calculation of the estimates to complete
construction contracts in progress. Project losses are provided for in their entirety in the
period in which such losses are determined, without reference to the percentage-of-completion. As
contracts can extend over one or more accounting periods, revisions in costs and earnings estimated
during the course of the work are reflected during the accounting period in which the facts that
required such revisions become known.
The asset “costs and estimated earnings in excess of billings on uncompleted contracts”
represents revenue recognized in excess of amounts billed. The liability “billings in excess of
costs and estimated earnings on uncompleted contracts” represents billings in excess of revenue
recognized.
We recognize revenue in our construction materials segment on the sale of our concrete and
aggregate products at the time of delivery.
We recognize revenue in our construction materials testing segment on the sale of our
professional services at the time services are provided.
Claims Receivable:
Claims for additional contract revenue are recognized only to the extent that contract costs
relating to the claim have been incurred and evidence provides a legal basis for the claim. As of
December 31, 2006 the total amount of contract claims filed by the Company with various public
entities was $19,084,311. Of this amount, the Company’s portion of the claims total was
$15,088,871 and the balance of $3,995,440 pertains to other contractors’ claims.
Total claim amounts reported in the Company’s consolidated financial statements are
approximate and are subject to revision as final documentation, resolution of issues, settlements
progress and/or payments are received. Relative to the aforementioned claims, the Company had
recorded $3,521,080 in cumulative claims receivable as of December 31, 2005 to offset a portion of
costs incurred to-date on the claims. In June 2006, the Company settled its claim with Clark
County Public Works thereby reducing claims receivable by $1,791,404. In December 2006, the
Company finalized and filed its claim of approximately $7.1 million with the Federal Highway
Administration that resulted from the Gooseberry project and recorded $734,204 as claims
receivable. The claims receivable as of December 31, 2006 was $2,463,880. All claims receivable
amounts as of December 31, 2006 and 2005 are classified as long-term.
The Company has not accrued a liability related to the prime contractor or subcontractors’
claims as no liability would be deemed payable if their portion of the claims did not receive a
favorable outcome. Correspondingly, no receivable has been recorded for overhead and profit
included in their portion of the claims on the Company’s behalf.
Although the Company believes that the claims receivable amount represents a reasonably
conservative posture, any claims proceeds ultimately paid to the Company less than the aggregate
amount recorded on the balance sheet of $2,463,880, will decrease earnings. Conversely, a payment
for those same items in excess of $2,463,880, will result in increased income.
A common and customary practice in construction contracts is the owner’s withholding of a
portion of the contract in the form of retention. Retention practices vary from contract to
contract, but in general, retention (usually between 5% to 10% of the contract) is withheld from
each progress payment by the owner and then paid upon satisfactory completion of the contract.
Contract proceeds comprising retention are included in the Company’s
balance sheet in accounts receivable. The portion of accounts receivable pertaining to
retention withheld on the contracts for which claims have been filed amounts to $879,763 and
$880,763 as of December 31, 2006 and 2005.
35
Table of Contents
MEADOW VALLEY CORPORATION AND SUBSIDIARIES
NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)
NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)
1. Summary of Significant Accounting Policies and Use of Estimates (Continued):
Claims Receivable (Continued):
The degree to which the Company is successful in prosecuting its claims may also impact the
amount of retention paid by the owner.
The Company believes that all retention amounts currently being held by the owners on the
contracts with outstanding claims will be paid in full in accordance with the contract terms.
Therefore, no allowance has been made to reduce the receivables due from the retention on the
disputed contracts.
Cash and Cash Equivalents:
The Company considers all highly liquid instruments purchased with an initial maturity of
three (3) months or less to be cash equivalents.
Restricted Cash:
At December 31, 2006 and 2005, funds in the amount of $605,243 and $1,267,090, respectively,
were held in trust, in lieu of retention, on certain of the Company’s construction contracts and
will be released to the Company after the contracts are completed.
Accounts Receivable, net:
Included in accounts receivable are trade receivables that represent amounts billed but
uncollected on completed construction contracts and construction contracts in progress as well as
other trade and non-trade receivables.
The Company follows the allowance method of recognizing uncollectible accounts receivable.
The allowance method recognizes bad debt expense based on a review of the individual accounts
outstanding and the Company’s prior history of uncollectible accounts receivable. At December 31,
2006 and 2005, the Company had established an allowance for potentially uncollectible accounts
receivable in the amounts of $395,243 and $326,112, respectively. During the years ended December
31, 2006, 2005 and 2004 the Company incurred bad debt expense (recovery) in the amounts of
$125,930, $(206,694) and $278,022, respectively. The Company records delinquent finance charges on
outstanding accounts receivable only if they are collected.
At December 31, 2006 and 2005 all of the Company’s accounts receivable were pledged as
collateral for the Company’s lines of credit.
Inventory, net:
Inventory,
which consists primarily of raw materials, is stated at the lower of cost,
determined by the first-in, first-out method, or market. Inventory quantities are determined by
physical measurements. At December 31, 2006 and 2005, the Company had an allowance for potentially
obsolete or slow moving inventory in the amounts of $200,000 and $244,271, respectively.
At December 31, 2006 and 2005, the Company’s entire inventory was pledged as collateral for
the Company’s lines of credit.
Property and Equipment:
Property and equipment are recorded at cost. Depreciation and amortization charged to
operations during the years ended December 31, 2006, 2005 and 2004 was $5,885,481, $4,499,044 and
$3,201,683, respectively. Depreciation is provided for on the straight-line method, over the
estimated useful lives. Leasehold improvements are recorded at cost and are amortized over their
estimated useful lives or the lease term, whichever is shorter. Mineral rights and pit development
costs are amortized over their estimated useful lives or the lease term, whichever is shorter.
36
Table of Contents
MEADOW VALLEY CORPORATION AND SUBSIDIARIES
NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)
NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)
1. Summary of Significant Accounting Policies and Use of Estimates (Continued):
Property and Equipment (Continued):
The estimated useful lives of property and equipment are:
Plants |
4 - 15 years | |
Computer equipment |
3 - 5 years | |
Equipment |
3 - 10 years | |
Vehicles |
3 - 10 years | |
Office furniture and equipment |
5 - 7 years | |
Leasehold improvements |
2 - 10 years | |
Building |
39 years |
At December 31, 2006 and 2005, all property and equipment were pledged as collateral for the
Company’s lines of credit, notes payable or capital lease obligations.
Income Taxes:
The Company accounts for income taxes in accordance with the Statement of Financial Accounting
Standards No. 109, “Accounting for Income Taxes” (“SFAS 109”). SFAS 109 requires the Company to
recognize deferred tax assets and liabilities for the expected future tax consequences of events
that have been recognized in a Company’s financial statements or tax returns. Under this method,
deferred tax assets and liabilities are determined based on the difference between the financial
statement carrying amounts and tax basis of assets and liabilities using enacted tax rates in
effect in the years in which the differences are expected to reverse. Prior to 2005, the Company
filed consolidated tax returns with MVCI and RMI. The Company absorbed the net income of MVCI and
RMI pursuant to a tax sharing agreement, which called for any income tax receivable or payable to
be remitted to, or paid by, the Company. As a result of the public offering of RMI’s stock, RMI can
no longer include its income as a part of the Company’s consolidated tax return and files its own
tax return in its respective tax jurisdictions.
Fair Value of Financial Instruments:
The carrying amounts of financial instruments including cash, restricted cash, costs and
estimated earnings in excess of billings on uncompleted contracts, certain current maturities of
long-term debt, billings in excess of costs and estimated earnings on uncompleted contracts,
accrued liabilities and long-term debt approximate fair value based on their short maturities or on
borrowing rates currently available to the Company for loans with similar terms and maturities.
The carrying amount of long-term debt approximates fair value because the interest rates on
these instruments approximate the rates at which the Company could borrow at December 31, 2006 and
2005.
Accounting for the Impairment of Long-Lived Assets and Long-Lived Assets to Be Disposed of:
The Company reviews property and equipment for impairment whenever events or changes in
circumstances indicate that the carrying amount of an asset may not be recoverable. Recoverability
of assets to be held and used is measured by a comparison of the carrying amount of an asset to
future net cash flows expected to be generated by the asset. If such assets are considered to be
impaired, the impairment recognized is measured by the amount by which the carrying amount of the
assets exceeds the fair value of the assets. Assets to be disposed of are reported at the lower of
the carrying amount or fair value less costs to sell.
Earnings per Share:
Statement of Financial Accounting Standards No. 128, “Earnings per Share,” (“SFAS 128”)
provides for the calculation of Basic and Diluted earnings per share. Basic earnings per share
includes no dilution and is computed by dividing income available to common shareholders by the
weighted average number of common shares
outstanding for the period. Diluted earnings per share reflect the potential dilution of
securities that could share in the earnings of an entity.
37
Table of Contents
MEADOW VALLEY CORPORATION AND SUBSIDIARIES
NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)
NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)
1. Summary of Significant Accounting Policies and Use of Estimates (Continued):
Stock-Based Compensation:
Both the Company and RMI have stock-based compensation plans. Effective January 1, 2006, the
Company and RMI adopted the fair value recognition provisions of Statement of Financial Accounting
Standards No. 123 (revised 2004), “Share-Based Payment” (“SFAS 123R”), using the modified
prospective transition method and therefore neither have restated results for prior periods. Under
this transition method, stock-based compensation expense for the year ended December 31, 2006
includes compensation expense for all stock-based compensation awards granted prior to, but not yet
vested as of January 1, 2006, based on the grant date fair value estimated in accordance with the
original provision of Statement of Financial Accounting Standards No. 123, “Accounting for
Stock-Based Compensation” (“SFAS 123”). Stock-based compensation expense for all stock-based
compensation awards granted after January 1, 2006 is based on the grant-date fair value estimated
in accordance with the provisions of SFAS 123R. The Company and RMI recognize these compensation
costs on a straight-line basis over the requisite service period of the award, which is the option
vesting term of three years.
The Company and RMI estimate fair value using the Black-Scholes valuation model. Assumptions
used to estimate compensation expense are determined as follows:
| • | Expected term is determined using an average of the contractual term and vesting period of the award; | ||
| • | Expected volatility is measured using a calculated average of historical daily changes in the market price of the Company’s common stock over the expected term of the award; | ||
| • | Risk-free interest rate is equivalent to the implied yield on zero-coupon U.S. Treasury bonds with a remaining maturity equal to the expected term of the awards; and, | ||
| • | Forfeitures are based on the history of cancellations of awards granted by both companies and management’s analysis of potential forfeitures. |
Prior to the adoption of SFAS 123R, the Company and RMI recognized stock-based compensation
expense in accordance with Accounting Principles Board Opinion No. 25, “Accounting for Stock Issued
to Employees” (“APB 25”). In March 2005, the SEC issued Staff Accounting Bulletin No. 107 (“SAB
107”) regarding the SEC’s interpretation of SFAS 123R and the valuation of share-based payments for
public companies. The Company and RMI have applied the provisions of SAB 107 in their adoption of
SFAS 123R. See Note 2 to the consolidated financial statements for a further discussion on
stock-based compensation.
38
Table of Contents
MEADOW VALLEY CORPORATION AND SUBSIDIARIES
NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)
NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)
1. Summary of Significant Accounting Policies and Use of Estimates (Continued):
Stock-Based Compensation (Continued):
The following table illustrates the effect on net income and net income per share if the
Company and RMI had applied the fair value recognition provisions of SFAS 123 to options granted
under the stock option plans, non-vested stock awards granted and shares issued under their
respective plans in the years ended December 31, 2005 and 2004. For purposes of pro forma
disclosures, the value of the options is estimated using the Black-Scholes option-pricing formula
and amortized to expense over the options’ vesting periods using the straight line method.
| Years Ended December 31, | ||||||||
| 2005 | 2004 | |||||||
Net income, as reported |
$ | 4,203,719 | $ | 573,639 | ||||
Add: Stock-based employee compensation expense included
in reported income, net of related tax effects |
— | — | ||||||
Deduct: Total stock-based employee compensation expense
determined
under fair value based methods for all awards, net of
related tax effects |
(157,146 | ) | (92,852 | ) | ||||
Pro forma net income |
$ | 4,046,573 | $ | 480,787 | ||||
Basic net income per common share |
||||||||
As reported |
$ | 1.11 | $ | 0.16 | ||||
Pro forma |
1.07 | 0.13 | ||||||
Diluted net income per common share |
||||||||
As reported |
$ | 1.01 | $ | 0.15 | ||||
Pro forma |
0.97 | 0.13 | ||||||
Recent Accounting Pronouncements:
In September 2006, the SEC issued SAB No. 108, “Considering the Effects of Prior Year
Misstatements when Quantifying Misstatements in Current Year Financial Statements,” to address
diversity in practice in quantifying financial statement misstatements. SAB No. 108 requires that
the Company quantify misstatements based on their impact on each of its financial statements and
related disclosures. SAB No. 108 is effective as of the end of the 2006 fiscal year, allowing a
one-time transitional cumulative effect adjustment to retained earnings as of January 1, 2006 for
errors that were not previously deemed material, but are material under the guidance in SAB No.
108. The adoption of SAB No. 108 did not have a material effect on its financial statements.
In September 2006, the FASB issued SFAS No. 158, “Employer’s Accounting for Defined Benefit
Pension and Other Postretirement Plans — an amendment of FASB Statements No. 87, 88, 106, and
132(R).” SFAS No. 158 requires the recognition of the overfunded or underfunded status of defined
benefit and retiree medical plans as an asset or liability in the Company’s 2006 year-end balance
sheet, with changes in the funded status recognized through comprehensive income in the year in
which they occur. SFAS No. 158 also requires the Company to measure the funded status of defined
benefit and retiree medical plans as of the Company’s year-end balance sheet date no later than
2008. The Company does not expect SFAS No. 158 will have a material effect on its financial
statements.
In September 2006, the FASB issued SFAS No. 157, “Fair Value Measurements,” which defines fair
value, establishes a framework for measuring fair value, and expands disclosures about fair value
measurements. SFAS No. 157 is effective for fiscal years beginning after November 15, 2007. The
Company does not expect SFAS No. 157 will have a material effect on its financial statements.
39
Table of Contents
MEADOW VALLEY CORPORATION AND SUBSIDIARIES
NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)
NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)
1. Summary of Significant Accounting Policies and Use of Estimates (Continued):
Recent Accounting Pronouncements (Continued):
In June 2006, the FASB issued FASB Interpretation No. 48, “An Interpretation of FASB Statement
No. 109,” which clarifies the accounting for uncertainty in income taxes recognized in a company’s
financial statements in accordance with FASB Statement No. 109, “Accounting for Income Taxes.”
This Interpretation prescribes a recognition threshold and measurement attribute for the financial
statement recognition and measurement of a tax position taken or expected to be taken in a tax
return. FIN No. 48 reflects the benefit recognition approach, where a tax benefit is recognized
when it is “more likely than not” to be sustained based on the technical merits of the position.
This Interpretation is effective for fiscal years beginning after December 15, 2006. The Company
does not expect FIN No. 48 will have a material effect on its financial statements.
In April 2006, the FASB issued FASB Staff Position (FSP) FIN No. 46(R)-6, “Determining the
Variability to Be Considered in Applying FASB Interpretation No. 46(R),” that became effective
beginning the third quarter of 2006. FSP FIN No. 46(R)-6 clarifies that the variability to be
considered in applying FASB Interpretation 46(R) shall be based on an analysis of the design of the
variable interest entity. The adoption of this FSP did not have a material effect on the Company’s
financial statements.
In March 2006, the FASB issued SFAS No. 156, “Accounting for Servicing of Financial Assets,”
which provides an approach to simplify efforts to obtain hedge-like (offset) accounting. This new
Statement amends SFAS No. 140, “Accounting for Transfers and Servicing of Financial Assets and
Extinguishments of Liabilities,” with respect to the accounting for separately recognized servicing
assets and servicing liabilities. SFAS No. 156 is effective for all separately recognized
servicing assets and liabilities as of the beginning of an entity’s fiscal year that begins after
September 15, 2006, with earlier adoption permitted in certain circumstances. The Company does not
expect SFAS No. 156 will have a material effect on its financial statements.
The FASB has revised its guidance on SFAS No. 133 Implementation Issues as of March 2006.
Several Implementation Issues were revised to reflect the issuance of SFAS No. 155, “Accounting for
Certain Hybrid Financial Instruments — an Amendment of FASB Statements No. 133 and 140,” in
February 2006. SFAS No. 155 allows any hybrid financial instrument that contains an embedded
derivative that otherwise would require bifurcation under SFAS No. 133, “Accounting for Derivative
Instruments and Hedging Activities” to be carried at fair value in its entirety, with changes in
fair value recognized in earnings. In addition, SFAS No. 155 requires that beneficial interests in
securitized financial assets be analyzed to determine whether they are freestanding derivatives or
contain an embedded derivative. SFAS No. 155 also eliminates a prior restriction on the types of
passive derivatives that a qualifying special purpose entity is permitted to hold. SFAS No. 155 is
applicable to new or modified financial instruments in fiscal years beginning after September 15,
2006, though the provisions related to fair value accounting for hybrid financial instruments can
also be applied to existing instruments. The Company does not expect SFAS No. 155 will have a
material effect on its financial statements.
2. Stock-Based Compensation:
On January 1, 2006, the Company adopted the fair value recognition provisions of SFAS 123R.
Prior to January 1, 2006, the Company accounted for share-based payments under the recognition and
measurement provisions of Accounting Principles Board Opinion No. 25, “Accounting for Stock Issued
to Employees” (“APB 25”), and related Interpretations, as permitted by SFAS 123. In accordance
with APB 25, no compensation cost was required to be recognized for options granted that had an
exercise price equal to the market value of the underlying common stock on the date of grant.
The Company adopted SFAS 123R using the modified prospective transition method. Under this
transition method, compensation cost recognized in the year ended December 31, 2006 includes: a)
compensation cost for all share-based payments granted prior to, but not yet vested as of January
1, 2006, based on the grant-date fair value estimated in accordance with the original provisions of
SFAS 123, and b) compensation cost for all share-based
payments granted subsequent to January 1, 2006, based on the grant-date fair value estimated
in accordance with the provisions of SFAS 123R. The results for the prior periods have not been
restated.
40
Table of Contents
MEADOW VALLEY CORPORATION AND SUBSIDIARIES
NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)
NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)
2. Stock-Based Compensation (Continued):
The Company recognizes expected tax benefits related to employee stock based compensation as
awards are granted and the incremental tax benefit or liability when related awards are deductible.
No stock-based compensation costs were recognized in expense in the years ended December 31, 2005
and 2004.
The Company and RMI both have individual stock-based compensation plans. Meadow Valley
Corporation’s accompanying consolidated financial statements and these related notes to financial
statements have been presented on a consolidated basis and therefore include RMI’s stock-based
compensation information. The information below is presented to show disclosures related to both
the Company’s and RMI’s individual stock-based compensation plans. Under the sub-heading “Meadow
Valley Corporation Equity Incentive Plan” of this note, information is only for the Company’s plan,
with the exception of information presented that is directly related to the consolidation of the
accompanying financial statements and this information is indicated as “consolidated”. Under the
sub-heading “Ready Mix, Inc. Equity Incentive Plan” of this note, information is only for RMI’s
plan.
Meadow Valley Corporation Equity Incentive Plan:
In 2004, the Company adopted the 2004 Equity Incentive Plan (“2004 Plan”). The 2004 Plan
permits the granting of any or all of the following types of awards: (1) incentive and nonqualified
stock options, (2) stock appreciation rights, (3) stock awards, restricted stock and stock units,
and (4) other stock or cash-based awards. In connection with any award or any deferred award,
payments may also be made representing dividends or their equivalent.
The 2004 Plan authorizes the issuance of up to 1,200,000 shares of Common Stock, all of which
were previously reserved for issuance under the Company’s prior plan. Shares of Common Stock
covered by an award granted under the 2004 Plan will not be counted as used unless and until they
are actually issued and delivered to a participant. As of December 31, 2006, 90,149 shares were
available for future grant under the 2004 Plan. The stock options have terms from five to ten
years and may be exercised after issuance as follows: 33.3% after one year of continuous service,
66.6% after two years of continuous service and 100% after three years of continuous service. The
exercise price of each option is equal to the market price of the Company’s common stock on the
date of the grant.
The Company uses the Black-Scholes option pricing model to estimate fair value of stock-based
awards with the following assumptions for the indicated periods:
| Awards during | ||||||||
| the year ended | Awards prior to | |||||||
| December 31, 2006 | January 1, 2006 | |||||||
Dividend yield |
0 | % | 0 | % | ||||
Expected volatility |
66.25 | % | 23.94% - 82.23 | % | ||||
Weighted-average expected volatility |
66.25 | % | 49.14 | % | ||||
Risk-free interest rate |
5.00 | % | 5.00 | % | ||||
Expected life of options (in years) |
3 | 3 | ||||||
Weighted-average grant-date fair value |
$ | 4.81 | $ | 1.15 | ||||
41
Table of Contents
MEADOW VALLEY CORPORATION AND SUBSIDIARIES
NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)
NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)
2. Stock-Based Compensation (Continued):
The following table summarizes the Company’s stock option activity during the year ended
fiscal 2006:
| Weighted Average | ||||||||||||||||||||
| Weighted Average | Remaining | Aggregate | Aggregate | |||||||||||||||||
| Exercise Price | Contractural | Fair | Intrinsic | |||||||||||||||||
| Shares | per Share | Term1 | Value | Value2 | ||||||||||||||||
Outstanding January 1, 2006 |
494,857 | 3.34 | 4.93 | $ | 554,982 | |||||||||||||||
Granted |
85,000 | 10.11 | 408,850 | |||||||||||||||||
Exercised |
(144,647 | ) | 2.76 | (144,913 | ) | $ | 1,135,441 | |||||||||||||
Forfeited or expired |
(668 | ) | 1.46 | (548 | ) | |||||||||||||||
Outstanding December 31, 2006 |
434,542 | 4.86 | 3.98 | $ | 818,371 | $ | 2,298,228 | |||||||||||||
Exercisable December 31, 2006 |
339,542 | 3.41 | 3.76 | $ | 357,721 | $ | 2,287,128 | |||||||||||||
| 1 | Remaining contractual term is presented in years. | |
| 2 | The aggregate intrinsic value is calculated as the difference between the exercise price of the underlying awards and the closing price of the Company’s common stock as of December 31, 2006, for those awards that have an exercise price currently below the closing price as of December 31, 2006. Awards with an exercise price above the closing price as of December 31, 2006 are considered to have no intrinsic value. |
A summary of the status of the Company’s nonvested shares as of December 31, 2006 and
changes during the year ended December 31, 2006 is presented below:
| Weighted Average | ||||||||
| Grant-Date | ||||||||
| Shares | Fair Value | |||||||
Nonvested stock options at January 1, 2006 |
124,000 | $ | 1.76 | |||||
Granted |
85,000 | 4.81 | ||||||
Vested |
(114,000 | ) | 1.01 | |||||
Forfeited |
— | — | ||||||
Nonvested stock options at December 31, 2006 |
95,000 | $ | 4.85 | |||||
During the year ended December 31, 2006 the Company recognized consolidated compensation
expense of $267,110, of which $161,427 was related to RMI’s stock-based compensation plan, and the
Company recognized a tax benefit of $21,555 related thereto. As of December 31, 2006, there was
$455,718 of total unrecognized compensation cost, net of $10,901 attributable to estimated
forfeitures based upon an approximate forfeiture rate of 9%, related to nonvested stock options
granted under the 2004 Plan. That cost is expected to be recognized over the weighted average
vesting period of 2.8 years. Awards granted during the year ended December 31, 2006, total 85,000
options, which were granted on November 30, 2006, with an exercise price of $10.11. During the
year ended December 31, 2006, 668 options were forfeited, all of which were vested.
During the year ended December 31, 2006, the Company received proceeds of $399,616, as a
result of the exercise of common stock options.
Ready Mix, Inc. Equity Incentive Plan:
In 2005, RMI adopted the 2005 Equity Incentive Plan (“2005 Plan”). The 2005 Plan permits the
granting of any or all of the following types of awards: (1) incentive and nonqualified stock
options, (2) stock appreciation rights, (3) stock awards, restricted stock and stock units, and (4)
other stock or cash-based awards. In connection with any award or any deferred award, payments may
also be made representing dividends or their equivalent.
42
Table of Contents
MEADOW VALLEY CORPORATION AND SUBSIDIARIES
NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)
NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)
2. Stock-Based Compensation (Continued):
RMI has reserved 675,000 shares of its common stock for issuance under the 2005 Plan. Shares
of common stock covered by an award granted under the 2005 Plan will not be counted as used unless
and until they are actually issued and delivered to a participant. As of December 31, 2006,
324,375 shares were available for future grant under the 2005 Plan. The term of the stock options
are five years and may be exercised after issuance as follows: 33.3% after one year of continuous
service, 66.6% after two years of continuous service and 100% after three years of continuous
service. The exercise price of each option is equal to the market price of RMI’s common stock on
the date of grant.
RMI uses the Black-Scholes option pricing model to estimate fair value of stock-based awards
with the following assumptions for the indicated periods:
| Awards during | ||||||||
| the year ended | Awards prior to | |||||||
| December 31, 2006 | January 1, 2006 | |||||||
Dividend yield |
0 | % | 0 | % | ||||
Expected volatility |
39.10 | % | 21.4% - 23.3 | % | ||||
Weighted-average volatility |
39.10 | % | 21.55 | % | ||||
Risk-free interest rate |
5.00 | % | 5.00 | % | ||||
Expected life of options (in years) |
3 | 3 | ||||||
Weighted-average grant-date fair value |
$ | 3.33 | $ | 2.02 | ||||
The following table summarizes the stock option activity during the year ended fiscal 2006:
| Weighted Average | ||||||||||||||||||||
| Weighted Average | Remaining | Aggregate | Aggregate | |||||||||||||||||
| Exercise Price | Contractural | Fair | Intrinsic | |||||||||||||||||
| Shares | per Share | Term (1) | Value | Value (2) | ||||||||||||||||
Outstanding January 1, 2006 |
253,125 | $ | 11.12 | 3.89 | $ | 511,616 | ||||||||||||||
Granted |
100,000 | 10.35 | 333,000 | |||||||||||||||||
Exercised |
— | — | — | |||||||||||||||||
Forfeited or expired |
(2,500 | ) | 11.00 | (4,875 | ) | |||||||||||||||
Outstanding December 31, 2006 |
350,625 | $ | 10.90 | 3.65 | $ | 839,741 | $ | 98,038 | ||||||||||||
Exercisable December 31, 2006 |
83,541 | $ | 11.12 | 3.14 | $ | 168,912 | $ | 7,679 | ||||||||||||
| (1) | Remaining contractual term is presented in years. | |
| (2) | The aggregate intrinsic value is calculated as the difference between the exercise price of the underlying awards and the closing price of RMI’s common stock as of December 31, 2006, for those awards that have an exercise price currently below the closing price as of December 31, 2006. Awards with an exercise price above the closing price as of December 31, 2006 are considered to have no intrinsic value. |
A summary of the status of RMI’s nonvested shares as of December 31, 2006 and changes
during the year ended December 31, 2006 is presented below:
| Weighted Average | ||||||||
| Grant-Date | ||||||||
| Shares | Fair Value | |||||||
Nonvested stock options at January 1, 2006 |
253,125 | $ | 2.02 | |||||
Granted |
100,000 | 3.33 | ||||||
Vested |
(83,541 | ) | 2.02 | |||||
Forfeited |
(2,500 | ) | 1.95 | |||||
Nonvested stock options at December 31, 2006 |
267,084 | $ | 2.51 | |||||
43
Table of Contents
MEADOW VALLEY CORPORATION AND SUBSIDIARIES
NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)
NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)
2. Stock-Based Compensation (Continued):
During the year ended December 31, 2006 RMI recognized compensation expense of $161,427 and a
tax benefit of $10,198, related thereto. As of December 31, 2006, there was $508,801 of total
unrecognized compensation cost, net of $7,487 attributable to estimated forfeitures, related to
nonvested stock options granted under the 2005 Plan. That cost is expected to be recognized over
the weighted average vesting period of 2.36 years. The total fair value of 83,541 options vested
during the year ended December 31, 2006, was $168,912. Awards granted during the year ended
December 31, 2006, total 100,000 options, which were granted on November 30, 2006, with an exercise
price of $10.35. During the year ended December 31, 2006, 2,500 options were forfeited, of which,
833 options were vested.
3. Note Receivable:
During the year ended December 31, 2006, the Company sold its minority interest in a related
party, LAM Contracting, LLC (“LAM”) to LAM’s majority owner. The Company sold its interest in LAM
for $793,540 that is to be paid with an initial payment of $100,000 and over six years with
quarterly payments of $32,647 including interest at 4%. As of December 31, 2006, $641,859 is due
to the Company.
4. Concentration of Credit Risk:
The Company maintains cash balances at various financial institutions. Deposits not to exceed
$100,000 for each institution are insured by the Federal Deposit Insurance Corporation. At
December 31, 2006 and 2005, the Company has uninsured cash, cash equivalents, and restricted cash
in the amounts of approximately $33,000,000 and $27,000,000, respectively.
The Company’s business activities and accounts receivable are with customers in the
construction industry and various governmental authorities and municipalities located primarily in
Nevada and Arizona. The Company performs ongoing credit evaluations of its customers and maintains
allowances for potential credit losses.
5. Accounts Receivable, net:
Accounts receivable, net consists of the following:
| December 31, | ||||||||
| 2006 | 2005 | |||||||
Contracts in progress |
$ | 11,781,074 | $ | 12,101,708 | ||||
Contracts in progress — retention |
3,928,480 | 3,075,487 | ||||||
Completed contracts |
9,481 | 39,480 | ||||||
Completed contracts — retention |
964,255 | 1,044,929 | ||||||
Other trade receivables |
9,468,930 | 9,135,832 | ||||||
Other receivables |
233,786 | 68,316 | ||||||
| 26,386,006 | 25,465,752 | |||||||
Less: Allowance for doubtful accounts |
(395,243 | ) | (326,112 | ) | ||||
| $ | 25,990,763 | $ | 25,139,640 | |||||
44
Table of Contents
MEADOW VALLEY CORPORATION AND SUBSIDIARIES
NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)
NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)
6. Contracts in Progress:
Costs and estimated earnings in excess of billings and billings in excess of costs and
estimated earnings on uncompleted contracts consist of the following:
| December 31, | ||||||||
| 2006 | 2005 | |||||||
Costs incurred on uncompleted contracts |
$ | 200,904,026 | $ | 165,582,867 | ||||
Estimated earnings to date |
17,742,674 | 2,196,947 | ||||||
| 218,646,700 | 167,779,814 | |||||||
Less: billings to date |
(225,758,594 | ) | (171,690,908 | ) | ||||
| $ | (7,111,894 | ) | $ | (3,911,094 | ) | |||
Included in the accompanying consolidated balance sheets under the following captions:
| December 31, | ||||||||
| 2006 | 2005 | |||||||
Costs and estimated earnings in excess of billings on
uncompleted contracts |
$ | 1,254,860 | $ | 1,991,993 | ||||
Billings in excess of costs and estimated earnings on
uncompleted contracts |
(8,366,754 | ) | (5,903,087 | ) | ||||
| $ | (7,111,894 | ) | $ | (3,911,094 | ) | |||
7. Property and Equipment:
Property and equipment consists of the following:
| December 31, | ||||||||
| 2006 | 2005 | |||||||
Land and building |
$ | 4,821,556 | $ | 2,647,763 | ||||
Plants |
13,683,086 | 9,417,309 | ||||||
Computer equipment |
964,178 | 880,530 | ||||||
Equipment |
21,214,671 | 16,762,810 | ||||||
Vehicles |
12,572,265 | 9,307,975 | ||||||
Office furniture and equipment |
123,831 | 90,029 | ||||||
Mineral rights and pit development |
97,488 | 194,977 | ||||||
Leasehold improvements |
497,654 | 286,607 | ||||||
Water rights |
2,250,000 | 2,250,000 | ||||||
| 56,224,729 | 41,838,000 | |||||||
Less: Accumulated depreciation and amortization |
(20,671,729 | ) | (15,609,927 | ) | ||||
| $ | 35,553,000 | $ | 26,228,073 | |||||
8. Accounts Payable:
Accounts payable consists of the following:
| December 31, | ||||||||
| 2006 | 2005 | |||||||
Trade |
$ | 11,917,720 | $ | 15,238,752 | ||||
Retentions |
1,380,394 | 3,282,806 | ||||||
| $ | 13,298,114 | $ | 18,521,558 | |||||
45
Table of Contents
MEADOW VALLEY CORPORATION AND SUBSIDIARIES
NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)
NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)
9. Accrued Liabilities:
Accrued liabilities consist of the following:
| December 31, | ||||||||
| 2006 | 2005 | |||||||
Compensation |
$ | 4,894,724 | $ | 4,125,792 | ||||
Taxes |
516,683 | 449,445 | ||||||
Insurance |
1,572,996 | 699,928 | ||||||
Other |
585,525 | 603,430 | ||||||
| $ | 7,569,928 | $ | 5,878,595 | |||||
10. Notes Payable:
Notes payable consists of the following:
| December 31, | ||||||||
| 2006 | 2005 | |||||||
Note payable, variable interest rate was 7.25% at December 31,
2005, with monthly principal payments of $4,121, due March 11,
2006, collateralized by equipment |
$ | — | $ | 12,363 | ||||
Notes payable, interest rates ranging from 6.21% to 7.05% with
combined monthly payments of $11,301, due dates ranging from
April 16, 2009 to August 27, 2009, collateralized by land |
1,154,158 | 1,213,271 | ||||||
Note payable, variable interest rate was 9.75% at December 31,
2006, with monthly principal payments of $21,429 plus interest,
due July 29, 2012, collateralized by mining water rights |
1,435,714 | 1,692,857 | ||||||
7.46% note payable, with a monthly payment of $13,867, due
May 26, 2021, collateralized by a building and land |
1,465,927 | — | ||||||
Non-interest bearing note payable, with monthly payments of $390,
due February 12, 2007, collateralized by equipment |
780 | 5,459 | ||||||
Line of credit, variable interest rate was 8.50% at December 31,
2006, interest only payments until December 31, 2008, 36 equal
monthly principal payments plus interest thereafter,
collateralized
by all of the Company’s assets (See Note 11) |
650,180 | 1,465,733 | ||||||
Line of credit for $2,023,102, variable interest was 9.0% at
December 31, 2006, interest only payments until December 31, 2007,
then principal plus interest payments, due December 31, 2010,
collateralized by all assets of the Company (See Note 11) |
990,669 | 1,675,044 | ||||||
Line of credit for $3,000,000, variable interest rate was 9.0% at
December 31, 2006, interest only payments until December 31, 2008,
then principal plus interest payments due December 31, 2011,
collateralized by all assets of the Company (See Note 11) |
250,000 | 250,000 | ||||||
Notes payable, interest rates ranging from 1.902% to 9.5% with
combined monthly payments of $48,861, due dates ranging from
September 28, 2008 to January 14, 2012, collateralized by
vehicles |
1,569,770 | 1,542,548 | ||||||
| $ | 7,517,198 | $ | 7,857,275 | |||||
46
Table of Contents
MEADOW VALLEY CORPORATION AND SUBSIDIARIES
NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)
NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)
10. Notes Payable (Continued):
Notes payable consists of the following (Continued):
| December 31, | ||||||||
| 2006 | 2005 | |||||||
Totals from previous page |
$ | 7,517,198 | $ | 7,857,275 | ||||
Notes payable, interest rates ranging from 1.90% to 7.25% with
combined monthly payments of $165,386, due dates ranging from
February 25, 2007 to July 20, 2011, collateralized by equipment |
3,804,405 | 5,232,301 | ||||||
Notes payable, interest rates ranging from 5.90% to 8.65% with
combined monthly payments of $149,602 plus interest, due dates
ranging from February 27, 2007 to January 10, 2012,
collateralized
by equipment |
6,465,766 | 1,393,861 | ||||||
Notes payable, non-interest bearing, with combined monthly payments of
$6,200, due dates ranging from August 15, 2008 to September 15, 2008
(Less unamortized discount of $7,581 - effective rate of 6.00%),
collateralized by vehicles |
125,187 | 228,341 | ||||||
Notes payable, interest rates ranging from 6.9% to 7.79% with combined
monthly payments of $45,141, due September 1, 2007, collateralized by
the Company’s general liability insurance policy |
350,806 | 230,158 | ||||||
Note payable, 8.18% interest rate with 44 monthly payments of
$7,353 and 1 payment of $111,853 due November 14, 2009,
collateralized by equipment |
310,644 | — | ||||||
Notes payable, interest rates of 3.848% with interest only
monthly
payments until April 1, 2006 then combined monthly payments of
$4,780 due December 1, 2009, collateralized by equipment |
158,004 | — | ||||||
| 18,732,010 | 14,941,936 | |||||||
Less: current portion |
(4,837,628 | ) | (3,518,892 | ) | ||||
| $ | 13,894,382 | $ | 11,423,044 | |||||
Following are maturities of long-term debt as of December 31, 2006 for each of the following years:
2007 |
$ | 4,837,628 | ||
2008 |
3,938,168 | |||
2009 |
4,856,601 | |||
2010 |
2,553,969 | |||
2011 |
1,262,802 | |||
Subsequent to 2011 |
1,282,842 | |||
| $ | 18,732,010 | |||
47
Table of Contents
MEADOW VALLEY CORPORATION AND SUBSIDIARIES
NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)
NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)
11. Lines of Credit:
As of December 31, 2006, the Company had a $3,000,000 line of credit loan agreement, with an
interest rate at Chase Manhattan Bank’s prime, plus .75%. The interest rate as of December 31,
2006 was 9.0%. The balance outstanding on the line of credit as of December 31, 2006 was $250,000.
The line of credit agreement allows for interest only payments until December 31, 2008. If the
agreement is not renewed by December 31, 2008 and a balance is outstanding, then the line of credit
converts into a term agreement requiring equal monthly principal plus interest payments through
December 31, 2011 and is collateralized by all of the Company’s assets. Under the terms of the
agreement, the Company is required to maintain a certain level of tangible net worth, a ratio of
total debt to tangible net worth and earnings before interest, tax, depreciation and amortization
(EBITDA). The Company and MVCI are also required to maintain a minimum cash flow to current portion
of long-term debt. As of December 31, 2006, the Company and MVCI were in compliance with these
covenants.
As of December 31, 2006, RMI had a $5,000,000 line of credit loan agreement, with an interest
rate at Chase Manhattan Bank’s prime, plus .25%. The interest rate as of December 31, 2006 was
8.5%. The balance outstanding on the line of credit as of December 31, 2006 was $650,180. The
line of credit agreement allows for interest only payments until December 31, 2008. If the
agreement is not renewed by December 31, 2008 and a balance is outstanding, then the line of credit
converts into a term agreement requiring equal monthly principal plus interest payments through
December 31, 2011 and is collateralized by all of RMI’s assets. Under the terms of the agreement,
the Company is required to maintain a certain level of tangible net worth, a ratio of total debt to
tangible net worth, and earnings before interest, tax, depreciation and amortization (EBITDA). The
Company and RMI are also required to maintain a minimum ratio of cash flow to current portion of
long term debt. As of December 31, 2006, the Company and RMI were compliant with the covenants.
As of December 31, 2006, the Company had a line of credit in the amount of $2,023,102, with an
interest rate at Chase Manhattan Bank’s prime, plus .75%. The interest rate as of December 31,
2006 was 9.0%. The balance outstanding on the line of credit as of December 31, 2006 was $990,669.
The line of credit agreement allows for interest only payments until December 31, 2007. Then the
line of credit converts into a term agreement requiring equal monthly principal plus interest
payments through December 31, 2010 and is collateralized by all of the Company’s assets. Under the
terms of the agreement, the Company is required to maintain a certain level of tangible net worth,
a ratio of total debt to tangible net worth and earnings before interest, tax, depreciation and
amortization (EBITDA). The Company and MVCI are also required to maintain a minimum cash flow to
current portion of long-term debt. As of December 31, 2006, the Company and MVCI were in
compliance with these covenants.
In addition to the lines of credit agreements mentioned above, the Company and RMI have each
established capital expenditure commitments in the amounts of $5,000,000 and $10,000,000,
respectively. The purposes of these commitments are to fund certain acquisitions of capital
equipment that the Company and RMI may need to improve capacity or productivity. As of December
31, 2006, the Company and RMI had approximately $2,650,000 and $4,750,000, respectively, available
to draw against under such commitments.
12. Related Party Transactions:
Revenue and Accounts Receivable:
During the year ended December 31, 2006, the Company sold its minority interest in a related
party, LAM Contracting, LLC (“LAM”) to LAM’s majority owner. During the years ended December 31,
2005 and 2004 the Company provided construction materials to LAM in the amounts of $152,630 and
$18,346, respectively. Included in accounts receivable at December 31, 2005 was $15,146 that was
due from the related party.
Professional Services:
During the years ended December 31, 2006, 2005 and 2004, a related party rendered professional
services to the Company in the amounts of $0, $164,202 and $0, respectively. During the years
ended December 31, 2006, 2005 and 2004, the Company incurred director fees of $91,000, $110,500 and
$40,000, respectively in aggregate to outside members of the board of directors. At December 31,
2006 and 2005, $91,000 and $124,625 were due to related parties which included amounts due to
outside directors.
48
Table of Contents
MEADOW VALLEY CORPORATION AND SUBSIDIARIES
NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)
NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)
12. Related Party Transactions (Continued):
Subcontractor/Supplier:
LAM provided materials, services and equipment used in the Company’s construction service
business during the years ended December 31, 2005 and 2004 in the amounts of $7,740 and $44,593,
respectively. At December 31, 2005 there were no liabilities due to related parties from
subcontracts and supplies.
13. Income Taxes:
The provisions for income tax expense from operations consist of the following:
| For the Years Ended December 31, | ||||||||||||
| 2006 | 2005 | 2004 | ||||||||||
Current |
$ | (3,167,174 | ) | $ | (372,102 | ) | $ | (5,919 | ) | |||
Deferred |
3,389 | (2,198,853 | ) | (310,885 | ) | |||||||
| $ | (3,163,785 | ) | $ | (2,570,955 | ) | $ | (316,804 | ) | ||||
The Company’s deferred tax asset (liability) consists of the following:
| December 31, | ||||||||
| 2006 | 2005 | |||||||
Deferred tax asset: |
||||||||
Nonqualified stock-based
compensation |
$ | 25,991 | $ | — | ||||
Allowance for bad debt and other |
462,216 | 417,186 | ||||||
Inventory allowance |
72,000 | 87,938 | ||||||
NOL carryforward |
992 | 255,600 | ||||||
| 561,199 | 760,724 | |||||||
Deferred tax liability: |
||||||||
Depreciation |
(2,974,857 | ) | (3,177,771 | ) | ||||
Net deferred tax liability |
$ | (2,413,658 | ) | $ | (2,417,047 | ) | ||
For the years ended December 31, 2006, 2005 and 2004, the effective tax rate differs from the
federal statutory rate primarily due to state income taxes and permanent differences, as follows:
| For the Years Ended December 31, | ||||||||||||
| 2006 | 2005 | 2004 | ||||||||||
Statutory rate of 34% applied to
income before income taxes |
$ | 3,024,000 | $ | 2,401,000 | $ | 303,000 | ||||||
State taxes, net of federal benefit |
202,000 | 140,000 | 18,000 | |||||||||
Increase (decrease) in income taxes
resulting from: |
||||||||||||
Non-Deductible items |
40,000 | 30,000 | 22,000 | |||||||||
Domestic production
activities deduction |
(102,000 | ) | — | — | ||||||||
Change in combined tax rate |
— | — | (27,000 | ) | ||||||||
| $ | 3,164,000 | $ | 2,571,000 | $ | 316,000 | |||||||
In 2006 the Company received $599,827 and $81,960 in tax benefits due to the realization of
past net operating loss carryforward amounts and alternative minimum tax carryforward amounts,
respectively. At December 31, 2006 the Company has $2,754 in Federal net operating loss
carryforward amounts which expire in 2021.
49
Table of Contents
MEADOW VALLEY CORPORATION AND SUBSIDIARIES
NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)
NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)
14. Commitments and Contingencies:
The Company purchased a building and moved its main office in Phoenix, Arizona in December
2006. The Company leases additional office space, batch plants, equipment, mixer trucks and
property under leases and raw material purchase obligations expiring in various years through 2016.
Rents and purchase obligations under the aforementioned operating leases and purchase agreements
were $6,126,141, $6,951,970 and $8,578,975 for the years ended December 31, 2006, 2005 and 2004,
respectively.
Minimum future rental payments under non-cancelable operating leases as of December 31, 2006
for each of the following years and in aggregate are:
| For the Years Ending December 31, | Amount | |||
2007 |
$ | 3,469,929 | ||
2008 |
2,895,395 | |||
2009 |
2,250,898 | |||
2010 |
1,384,570 | |||
2011 |
603,027 | |||
| $ | 10,603,819 | |||
Minimum future purchase agreements under non-cancelable purchase agreements as of December 31,
2006 for each of the following years and in aggregate are:
| For the Years Ending December 31, | Amount | |||
2007 |
$ | 3,720,444 | ||
2008 |
3,630,444 | |||
2009 |
3,549,644 | |||
2010 |
2,802,935 | |||
2011 |
2,385,000 | |||
Subsequent to 2011 |
11,491,250 | |||
| $ | 27,579,717 | |||
The Company has entered into employment contracts with its executive officers and key
employees that provide for an annual salary, issuance of the Company’s common stock and various
other benefits
and incentives. RMI has entered into employment contracts with two of its executive officers
that provide for an annual salary, issuance of RMI’s common stock and various other benefits and
incentives. As of December 31, 2006, the total commitments, excluding benefits and incentives, for
each of the following years and in aggregate are:
| For the Years Ending December 31, | Amount | |||
2007 |
$ | 1,347,000 | ||
2008 |
966,333 | |||
2009 |
441,667 | |||
| $ | 2,755,000 | |||
The Company is the lessee of vehicles and equipment under capital leases expiring in various
years through 2008. The assets and liabilities under a capital lease are initially recorded at the
lower of the present value of the minimum lease payments or the fair value of the asset. Each
asset is depreciated over the lesser of the expected useful life or the lease term. Depreciation
on the assets under capital leases charged to expense in 2006, 2005 and 2004 was $353,768, $347,729
and $231,808, respectively. At December 31, 2006 and 2005, property and equipment included
$892,302 and $1,222,413, net of accumulated depreciation, of vehicles and equipment under capital
leases.
50
Table of Contents
MEADOW VALLEY CORPORATION AND SUBSIDIARIES
NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)
NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)
14. Commitments and Contingencies (Continued):
Minimum future lease payments under capital leases as of December 31, 2006 for each of the
following years and in aggregate are:
| For the Years Ending December 31, | Amount | |||
2007 |
$ | 366,005 | ||
2008 |
105,947 | |||
Total minimum payments |
471,952 | |||
Less: amount representing interest |
(36,954 | ) | ||
Present value of net minimum lease payment |
434,998 | |||
Less: current portion |
(332,898 | ) | ||
| $ | 102,100 | |||
Interest rates on capitalized leases vary from 5.07% to 6.75% and are imputed based on the
lower of the Company’s incremental borrowing rate at the inception of the lease or the lessor’s
implicit rate of return.
The Company has agreed to indemnify its officers and directors for certain events or
occurrences arising as a result of the officer or director serving in such capacity. The term of
the indemnification period is for the officer’s or director’s lifetime. The maximum potential
amount of future payments the Company could be required to make under these indemnification
agreements is unlimited. However, the Company has a directors and officers’ liability insurance
policy that enables it to recover a portion of any future amounts paid up to $10.0 million. As a
result of its insurance policy coverage and no current or expected litigation, the Company believes
the estimated fair value of these indemnification agreements is minimal and has no liabilities
recorded for these agreements as of December 31, 2006.
The Company enters into indemnification provisions under its agreements with other companies
in its ordinary course of business, typically with business partners, customers, landlords, lenders
and lessors. Under these
provisions the Company generally indemnifies and holds harmless the indemnified party for
losses suffered or incurred by the indemnified party as a result of the Company’s activities or, in
some cases, as a result of the indemnified party’s activities under the agreement. The maximum
potential amount of future payments the Company could be required to make under these
indemnification provisions is unlimited. The Company has not incurred material costs to defend
lawsuits or settle claims related to these indemnification agreements. As a result, the Company
believes the estimated fair value of these agreements is minimal. Accordingly, the Company has no
liabilities recorded for these agreements as of December 31, 2006.
15. Minority Interest in Consolidated Subsidiary:
On August 24, 2005, the Company’s construction materials subsidiary, Ready Mix, Inc. (“RMI”)
began trading on the American Stock Exchange under the trading symbol “RMX.” The initial public
offering of 1,782,500 shares, including the exercise of the over-allotment option, was sold for
$11.00 per share. The Company retains ownership of 2,025,000 shares, representing approximately
53% of the total outstanding shares of RMI. Proceeds from the initial public offering were used by
RMI for the purchase of plant and equipment, repayment of debt to the Company and working capital.
Net proceeds realized through the offering and approximately 47% of RMI’s net income from the
date of the offering through December 31, 2006 and 2005 are reported on the December 31, 2006 and
2005 balance sheets under the caption “Minority Interest in Consolidated Subsidiary.” Also, the
portion of net income referenced above is reported on the related statements of operations for the
years ended December 31, 2006 and 2005 under the caption “Minority Interest in Consolidated
Subsidiary.”
51
Table of Contents
MEADOW VALLEY CORPORATION AND SUBSIDIARIES
NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)
NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)
16. Stockholders’ Equity:
Preferred Stock:
The Company has authorized 1,000,000 shares of $.001 par value preferred stock to be issued,
with such rights, preferences, privileges, and restrictions as determined by the Board of
Directors.
Common Stock:
On October 23, 2006, the Company issued an additional 817,120 shares of common stock in a
private placement offering. The shares were issued with 81,712 warrants exercisable six months and
a day from October 23, 2006, the closing of the offering, at an exercise price of $12.60 per
warrant. The Company issued the shares at $9.00 per share which resulted in proceeds received
approximately in the amount of $6.6 million, which is net of offering costs of $.8 million. The
proceeds were used as working capital in order to secure additional bonding capacity. In
connection with this offering, the Company entered into a registration rights agreement with all of
the investors who purchased shares. The registration was declared effective by the SEC on November
17, 2006.
17. Litigation and Claim Matters:
The Company is a party to legal proceedings in the ordinary course of its business. With the
exception of those matters detailed below, the Company believes that the nature of these
proceedings (which generally relate to disputes between the Company and its subcontractors,
material suppliers or customers regarding payment for work performed or materials supplied) are
typical for a construction firm of its size and scope, and no other pending proceedings are deemed
to be materially detrimental and some claims may prove beneficial to its financial condition.
The following proceedings represent matters that may be material and have been referred to
legal counsel for further action:
Requests for Equitable Adjustment to Construction Contracts. The Company has made claims
as described below on the following contracts:
| (1) | Two contracts with the New Mexico State Highway and Transportation Department – The approximate total value of claims on these projects is $12,002,782 of which $8,336,931 is on behalf of MVCI and the balance of $3,665,851 is on behalf of the prime contractor or subcontractors. The primary issues are changed conditions, plan errors and omissions, contract modifications and associated delay costs. In addition, the projects were not completed within the adjusted contract time because of events giving rise to the claims. The prosecution of the claims will include the appropriate extensions of contract time to offset any potential liquidated damages. The trial date has been postponed, and no date has been scheduled as of the date of this report. | ||
| (2) | Clark County Public Works, Clark County, Nevada – A final ruling on November 1, 2004, by the three-member arbitration panel awarded the Company approximately $5,540,000, of which $2,100,000 was due to MVCI and the balance of $3,440,000 was due a subcontractor. The award included prejudgment interest and post-judgment interest, which continued to accrue at approximately $900 per day. The approximate total value of the claims ruled on above was $6,833,197, of which $2,211,947 was on behalf of MVCI and the balance of $4,621,250 was on behalf of a subcontractor. MVCI has not recognized any additional claim receivable related to this ruling since Clark County Public Works filed, on January 28, 2005 with the District Court, a Notice of and Motion to Vacate Arbitration Award. The County’s motion was heard on May 9, 2005 and was denied by the District Court, but was appealed to the Nevada Supreme Court. In 2004, the three-member arbitration panel made a partial ruling rejecting a significant portion of the original claim that was primarily asserted by another subcontractor on the project, which we refer to as the Shoring Entitlement claim. MVCI filed with the District Court a Notice of and Motion to Vacate Arbitration Award on the Shoring Entitlement. The motion was denied by the District Court and on February 7, 2005, MVCI filed an appeal to the Nevada Supreme Court. The primary issues related to the claim filed against Clark County Public Works were |
52
Table of Contents
MEADOW VALLEY CORPORATION AND SUBSIDIARIES
NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)
NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)
17. Litigation and Claim Matters (Continued):
| changed conditions, constructive changes, contract modifications and associated delay costs. A date has not yet been established for the Nevada Supreme Court to hear the appeals. On June 19, 2006, MVCI settled its $6,833,197 claim with Clark County for $5,110,000, of which $2,095,000 was placed in escrow pursuant to a binding arbitration agreement between MVCI and its subcontractor, Innovative Construction Systems, Inc. (“ICS”). MVCI then settled the pending claims with ICS during its preparation for the arbitration hearing. Both parties agreed to withdraw their respective actions with prejudice, which resulted in the release of $2.1 million from escrow to MVCI. | |||
| (3) | Federal Highway Administration – The approximate total value of claims on this project is $7.1 million, of which $6.8 million is on behalf of MVCI and the balance of $0.3 million is on behalf of a subcontractor. The primary issues are unforeseen conditions, changed conditions, plan errors and omissions, contract modifications and associated delay costs. In addition, the projects were not completed within the adjusted contract time because of events giving rise to the claims. On September 18, 2006 MVCI submitted a formal claim with the Federal Highway Administration. MVCI was informed on December 1, 2006 that a formal decision would not be provided until at least June 2007. |
The combined total of all outstanding claims as of December 31, 2006 is $19,084,311. MVCI’s
portion of the total claims is $15,088,871 and the balance pertaining to a prime contractor or
subcontractors’ claims is $3,995,440. Total claim amounts reported by MVCI are approximate and are
subject to revision as final documentation progresses and as issues are resolved and/or payments
made. Claim amounts do not include any prejudgment interest, if applicable. Relative to the
aforementioned claims, MVCI has recorded $2,463,880 in cumulative claims receivable to offset a
portion of costs incurred to date on the claims.
MVCI has not accrued a liability related to the prime contractor or subcontractors’ claims as
no liability would be deemed payable if their portion of the claims did not receive a favorable
final outcome. Correspondingly, no receivable has been recorded for overhead and profit included
in their portion of the claims on MVCI’s behalf.
Although MVCI believes that the claims receivable amount represents a reasonably conservative
posture, any claims proceeds ultimately paid to MVCI less than the aggregate amount recorded on the
balance sheet of $2,463,880, will decrease earnings. Conversely, a payment for those same items in
excess of $2,463,880 will result in increased income.
The portion of accounts receivable pertaining to retention withheld on the contracts for which
claims have been filed amounts to $879,763. The degree to which MVCI is successful in prosecuting
its claims may also impact the amount of retention paid by the owner. MVCI believes that all
retention amounts currently being held by the owners on the contracts with outstanding claims will
be paid in full in accordance with the contract terms. Therefore, no allowance has been made to
reduce the receivables due from the retention on the disputed contracts.
Lawsuits Filed Against Meadow Valley Contractors, Inc.
| (1) | Innovative Construction Systems, Inc. (“ICS”), District Court, Clark County, NV – ICS was a subcontractor to MVCI on several projects. ICS failed to make payments of payroll, pension fund contributions and other taxes for which the Internal Revenue Service garnished any future payments due ICS on MVCI’s projects. As a result, ICS failed to supply labor to perform its work and defaulted on its subcontracts. MVCI terminated the ICS subcontracts and performed the work with its own personnel. ICS alleged the subcontracts were wrongfully terminated and asserted numerous claims for damages. ICS total claims against MVCI were approximately $15,000,000. MVCI defended itself against the claims and filed counter-claims for approximately $3,200,000 seeking to recover the damages ICS caused MVCI through its failure to perform and satisfy its financial obligations. As such, no liability was recorded in the accompanying financial statements for any potential loss arising from the claim. In September 2003, a binding arbitration agreement was entered into between ICS and MVCI to stay all actions until the Clark County, Nevada Shoring Entitlement claim, as mentioned above, concluded, a decision rendered, payment received from the County, and the funds escrowed. As a result of the Clark County arbitration panel’s decision referenced above, MVCI requested binding |
53
Table of Contents
MEADOW VALLEY CORPORATION AND SUBSIDIARIES
NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)
NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)
17. Litigation and Claim Matters (Continued):
| arbitration concerning all remaining matters between MVCI and ICS. MVCI settled all matters with ICS during its preparation for the arbitration hearing. Both parties agreed to withdraw their respective actions with prejudice, which resulted in the release of $2.1 million from escrow to MVCI. MVCI’s remaining obligation to ICS is to continue its appeal to the Nevada Supreme Court of the Shoring Entitlement claim and to cooperate with ICS in passing through one of their remaining claims if they decide to pursue their rights to do so. | |||
| (2) | Johnson & Danley Construction Co., Inc. (“JDCC”), J.D. Materials, Inc. (“JDM”) and Joel T. Danley (“Danley”) (collectively “J&D”), Twelfth Judicial District, District of New Mexico – JDCC was the prime contractor and MVCI was a subcontractor to JDCC on one of the two contracts involved in MVCI’s disputes with the state of New Mexico. JDCC was also a subcontractor to MVCI on other contracts in New Mexico. JDM is the owner of an aggregate pit in Alamogordo, NM and leased the pit to MVCI under a mineral lease agreement. Danley is believed to be an officer and owner of JDCC and JDM. JDCC filed for Chapter 11 bankruptcy protection, which in accordance with the contract, resulted in the termination of its contract with the New Mexico State Highway and Transportation Department (“NMSHTD”). The payment and performance bonds supplied by JDCC in connection with the one contract for which JDCC was the prime contractor had been furnished by MVCI’s surety companies. MVCI indemnified the surety companies against losses and claims on the one contract. Upon JDCC’s termination, the NMSHTD entered into a takeover agreement with the surety companies who subsequently entered into an agreement with MVCI to complete the work. MVCI has successfully completed the projects. In its complaint, J&D alleged, among other things, that MVCI was partially responsible for the cause of its bankruptcy and sought damages in an undetermined amount. On February 10, 2003, J&D and MVCI entered into a settlement agreement for mutual consideration whereby the two parties dismissed their claims and counterclaims in their entirety. The parties have agreed to jointly prosecute their respective claims against the NMSHTD. | ||
| (3) | MVCI is defending a claimed preference, in the Third Judicial Court of Salt Lake County, in connection with a payment made to it by an insurance company, Southern America Insurance Company, in the approximate amount of $100,000. MVCI believes that the payment is not a preference, and is vigorously defending the action. | ||
| (4) | MVCI, through its insurance company, is providing a defense to the State of Arizona, pursuant to its obligations under its contract, for a complaint brought by the parents of Corey James and Michelle James in the Superior Court of the State of Arizona, in and for the County of Pinal. The Complaint, No. CV00400744, was filed on July 9, 2004. The complaint is a civil action titled John James, the Father of Decedent Corey James, Donna James, the mother of Decedent Corey James, Marjorie Surine, the Mother of Decedent Michelle James and Joseph Burkhamer, the Father of Decedent Michelle James, Plaintiffs, vs. The State of Arizona, a Body Politic; John Does and Jane Does 1-10; ABC Companies 1-5; and Black and White Corporations, Partnerships and/or Sole proprietorships 1-10, or Other Entities, Defendants. The complaint seeks damages from the State of Arizona for losses suffered by the plaintiffs as a result of a traffic accident. In January of 2006, Joseph Burkhamer, the father of decedent Michelle James, was dismissed from the complaint. MVCI denies responsibility for the accident and is vigorously defending the action. MVCI is unable to ascertain if any loss is probable or even estimatable and accordingly, has not accrued a liability related to this complaint as of December 31, 2006. |
54
Table of Contents
MEADOW VALLEY CORPORATION AND SUBSIDIARIES
NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)
NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)
18. Statement of Cash Flows:
Non-Cash Investing and Financing Activities:
The Company recognized investing and financing activities that affected assets and
liabilities, but did not result in cash receipts or payments. These non-cash activities are as
follows:
During the years ended December 31, 2006, 2005 and 2004, the Company financed the purchase of
property and equipment in the amounts of $6,409,452, $3,793,429 and $8,689,666, respectively.
During the year ended December 31, 2005, the Company refinanced a note payable in the amount of
$3,205,303.
During the years ended December 31, 2006, 2005 and 2004, the Company financed the purchase of
various insurance policies in the amounts of $477,747, $416,017 and $382,789, respectively.
During the year ended December 31, 2006 and 2005, the Company realized income tax benefits of
$144,879 and $884,083, respectively, as a result of disqualifying dispositions of incentive stock
options, which is included in income taxes payable and additional paid-in capital.
During the year ended December 31, 2006, the Company sold its minority interest in LAM to its
majority owner. The Company sold its interest in LAM for $793,540, which includes an initial
payment of $100,000 and quarterly payments to be paid over six years. The balance of this note
receivable at December 31, 2006 was $641,859.
19. Significant Customers:
For the years ended December 31, 2006, 2005 and 2004, the Company recognized a significant
portion of its revenue from the following Customers (shown as an approximate percentage of total
revenue):
| For the Years Ended December 31, | ||||||||||||
| 2006 | 2005 | 2004 | ||||||||||
A |
20.9 | % | 21.0 | % | 24.1 | % | ||||||
B |
5.1 | % | 11.6 | % | 6.8 | % | ||||||
At December 31, 2006 and 2005, amounts due from the aforementioned Customers included in
restricted cash and accounts receivables, are as follows:
| For the Years Ended December 31, | ||||||||
| 2006 | 2005 | |||||||
A |
$ | 1,874,446 | $ | 2,042,861 | ||||
B |
2,153,500 | 745,756 | ||||||
20. Employee Benefit Plan:
The Company maintains a 401(k) profit sharing plan allowing substantially all employees to
participate. Under the terms of the Plan, the employees may elect to contribute a portion of their
salary to the Plan. The matching contributions by the Company are at the discretion of the Board
of Directors, and are subject to certain limitations. For the years ended December 31, 2006, 2005
and 2004, the Company contributed $580,268, $437,363 and $330,545 to the Plan.
55
Table of Contents
MEADOW VALLEY CORPORATION AND SUBSIDIARIES
NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)
NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)
21. Earnings per Share:
Statement of Financial Accounting Standards No. 128, “Earnings per Share,” provides for the
calculation of Basic and Diluted earnings per share. Basic earnings per share includes no dilution
and is computed by dividing income available to common shareholders by the weighted average number
of common shares outstanding for the period. Diluted earnings per share reflect the potential
dilution of securities that could share in the earnings of an entity, as set forth below:
| For the Years Ended December 31, | ||||||||||||
| 2006 | 2005 | 2004 | ||||||||||
Weighted average common shares
outstanding |
4,328,160 | 3,783,089 | 3,601,250 | |||||||||
Dilutive effect of: |
||||||||||||
Stock options |
292,964 | 368,007 | 179,347 | |||||||||
Weighted average common shares
outstanding assuming dilution |
4,621,124 | 4,151,096 | 3,780,597 | |||||||||
All dilutive common stock equivalents are reflected in our earnings per share calculations.
Anti-dilutive common stock equivalents are not included in our earnings per share calculations. The
Company had anti-dilutive common stock equivalents as of December 31, 2006 and 2004, as described
below.
The Company’s diluted net income per common share for the year ended December 31, 2006 was
computed based on the weighted average number of shares of common stock outstanding during the
period and the weighted average number of options to purchase 434,542 shares at a range of $1.46 to
$10.11. The weighted average number of warrants to purchase 81,712 shares at $12.60 per share were
outstanding at December 31, 2006, but were not included in the computation of diluted net income
per common shares because the warrants’ exercise price was greater than the average market price of
the common share.
The Company’s diluted net income per common share for the year ended December 31, 2005 was
computed based on the weighted average number of shares of common stock outstanding during the
period and the weighted average number of options to purchase 494,857 shares at a range of $1.46 to
$9.38.
The Company’s diluted net income per common share for the year ended December 31, 2004 was
computed based on the weighted average number of shares of common stock outstanding during the
period and the weighted average number of options to purchase 588,300 shares at a range of $1.46 to
$3.875. The weighted average number of options to purchase 453,525 shares at a range of $4.00 to
$6.25 per share were outstanding during 2004, but were not included in the computation of diluted
net income per common shares because the options’ exercise price was greater than the average
market price of the common share.
22. Backlog:
The Company’s backlog (anticipated revenue from the uncompleted portions of awarded projects)
was approximately $89,500,000 at December 31, 2006, compared to approximately $68,400,000 at
December 31, 2005. At December 31, 2006, the entire Company’s backlog of work of $89,500,000
(unaudited) is scheduled for completion during 2007.
23. Subsequent Events:
In January 2007, the Company financed the purchase of a vehicle in the amount of $33,680. The
note payable obligation has an interest rate of 9.5%, a monthly payment of $710 and is due February
2012.
In February 2007, the Company financed the purchase of a vehicle in the amount of $29,345, net
of unamortized interest expense of $5,936. The note payable obligation has a stated interest rate
of 0%, however the Company discounted the note payable with an imputed interest rate of 7.5%.
Monthly payments are $588 and the note payable is due February 2012.
56
Table of Contents
MEADOW VALLEY CORPORATION AND SUBSIDIARIES
NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)
NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)
23. Subsequent Events (Continued):
In January and February 2007, the Company was awarded approximately $7.2 million in new
contracts.
In February 2007, the Board of Directors of the Company entered into a Rights Agreement with
its transfer agent, Corporate Stock Transfer, Inc., a Colorado corporation. The agreement provides
for a dividend distribution of one right for each outstanding share of common stock of the Company.
Each right entitles the holder to purchase one unit, which consists of one one-thousandths of a
share of Series A Participating Preferred Stock, $0.001 par value per share, at a purchase price of
$50.00 per unit following the distribution date until a person becomes an acquiring person. The
distribution date occurs upon the earlier of (1) ten business days following the first
public announcement or the date on which the Company has actual notice that an acquiring person has
become such, or (2) ten business days following the commencement of or announcement of an
intention to make a tender or exchange offer, which upon consummation of which would result in an
acquiring person become such. In the event that a person becomes an acquiring person, each holder
of a right will no longer have the right to purchase units of preferred stock, but instead will
thereafter have the right to receive, upon the exercise of the right, shares of common stock having
a current market price equal to two times the exercise price of $50.00 per unit.
24. Other Informative Disclosures:
The construction services segment of the Company generates revenue by providing construction
services, usually under terms of a contract with an owner or a subcontract with another contractor.
The construction services segment operates in Nevada, Arizona and southern Utah markets.
The construction materials segment manufactures and distributes ready mix concrete and sand
and gravel products in the Las Vegas, NV and Phoenix, AZ markets. Prospective customers include
concrete subcontractors, prime contractors, homebuilders, commercial and industrial property
developers, pool builders and homeowners. Construction materials sales first began from a single
location in March 1997 and, by the end of 2006, expanded to three locations in the Las Vegas, NV
vicinity, one location in the Moapa, NV vicinity and three locations in the Phoenix, AZ vicinity.
The construction materials testing segment of the Company generates revenue by providing
materials testing to all segments of the construction industry, which can be under terms of a
contract or as time and materials billable work with an owner or a subcontract with another
contractor. The construction materials testing segment operates in the Las Vegas, Nevada regional
market.
The following is a summary of certain financial information of the Company’s three main areas
of operations for 2006, 2005 and 2004:
| Construction | Construction | Construction | ||||||||||
| Services | Materials | Materials Testing | ||||||||||
For the twelve months ended
December 31, 2006 |
||||||||||||
Gross revenue |
$ | 112,948,370 | $ | 83,588,803 | $ | 546,548 | ||||||
Intercompany revenue |
(1,012,085 | ) | (436,865 | ) | (112,820 | ) | ||||||
Cost of revenue |
102,878,625 | 74,382,436 | 512,572 | |||||||||
Interest income |
615,365 | 394,779 | — | |||||||||
Interest expense |
(175,657 | ) | (163,229 | ) | — | |||||||
Depreciation and amortization |
2,438,374 | 3,439,208 | 7,899 | |||||||||
Income (loss) before taxes |
3,863,765 | 5,211,606 | (182,216 | ) | ||||||||
Income tax benefit (expense) |
(1,357,211 | ) | (1,872,331 | ) | 65,757 | |||||||
Net income (loss)* |
2,506,554 | 1,775,827 | (116,459 | ) | ||||||||
Total assets |
54,463,850 | 47,022,753 | 619,052 | |||||||||
57
Table of Contents
MEADOW VALLEY CORPORATION AND SUBSIDIARIES
NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)
NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)
24. Other Informative Disclosures (Continued):
| Construction | Construction | Construction | ||||||||||
| Services | Materials | Materials Testing | ||||||||||
For the twelve months ended December
31, 2005 |
||||||||||||
Gross revenue |
$ | 116,822,072 | $ | 67,734,424 | $ | — | ||||||
Intercompany revenue |
— | (683,633 | ) | — | ||||||||
Cost of revenue |
108,706,174 | 60,662,743 | — | |||||||||
Interest income |
466,901 | 173,574 | — | |||||||||
Interest expense |
(212,546 | ) | (227,341 | ) | — | |||||||
Intercompany interest income (expense) |
77,561 | (77,561 | ) | — | ||||||||
Depreciation and amortization |
2,088,144 | 2,410,900 | — | |||||||||
Income before taxes |
3,142,565 | 3,920,632 | — | |||||||||
Income tax expense |
(1,135,913 | ) | (1,435,042 | ) | — | |||||||
Net income * |
2,006,652 | 2,197,067 | — | |||||||||
Total assets |
47,109,736 | 39,906,794 | — | |||||||||
For the twelve months ended December
31, 2004 |
||||||||||||
Gross revenue |
$ | 108,175,663 | $ | 59,135,658 | $ | — | ||||||
Intercompany revenue |
(6,742 | ) | (472,915 | ) | — | |||||||
Cost of revenue |
107,834,595 | 52,508,936 | — | |||||||||
Interest income |
170,409 | 28,637 | — | |||||||||
Interest expense |
(209,615 | ) | (251,796 | ) | — | |||||||
Intercompany interest income (expense) |
113,182 | (113,182 | ) | — | ||||||||
Depreciation and amortization |
1,586,633 | 1,615,050 | — | |||||||||
Income (loss) before taxes |
(2,921,056 | ) | 3,811,499 | — | ||||||||
Income tax benefit (expense) |
1,054,728 | (1,371,532 | ) | — | ||||||||
Net income (loss) |
(1,866,328 | ) | 2,439,967 | — | ||||||||
Total assets |
42,915,047 | 22,413,785 | — | |||||||||
| * | Net income for the construction materials segment includes the minority interest deduction of $1,563,449 and $288,523 for the years ended December 31, 2006 and 2005, respectively. In addition, in 2005 net income has been re-allocated for comparative purposes. |
There are no differences in accounting principles between the operations. All centrally
incurred costs are allocated to the construction services operation. Beginning in 2005, an
administrative services fee has been allocated to the materials segment in the amount of $22,000
per month. Intercompany revenue is eliminated at cost to arrive at consolidated revenue and cost
of revenue.
25. Quarterly Financial Data, Unaudited:
| March 31, | June 30, | September 30, | December 31, | |||||||||||||
2006 |
||||||||||||||||
Revenue |
$ | 45,749,668 | $ | 48,316,869 | $ | 51,704,022 | $ | 49,751,392 | ||||||||
Gross profit |
4,747,913 | 4,766,927 | 4,043,279 | 5,751,969 | ||||||||||||
Income from operations |
1,988,971 | 2,053,758 | 1,692,828 | 2,412,712 | ||||||||||||
Net income |
863,958 | 873,727 | 885,266 | 1,542,971 | ||||||||||||
Basic net income per common share |
0.21 | 0.21 | 0.21 | 0.32 | ||||||||||||
Diluted net income per common share |
0.19 | 0.19 | 0.20 | 0.31 | ||||||||||||
Basic weighted average common shares
outstanding |
4,154,444 | 4,161,732 | 4,165,760 | 4,830,704 | ||||||||||||
Diluted weighted average common shares
outstanding |
4,476,559 | 4,481,183 | 4,470,241 | 5,056,513 | ||||||||||||
58
Table of Contents
MEADOW VALLEY CORPORATION AND SUBSIDIARIES
NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)
NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)
25. Quarterly Financial Data, Unaudited (Continued):
| March 31, | June 30, | September 30, | December 31, | |||||||||||||
2005 |
||||||||||||||||
Revenue |
$ | 39,926,013 | $ | 53,443,002 | $ | 47,083,476 | $ | 43,420,372 | ||||||||
Gross profit |
1,946,110 | 3,638,552 | 4,543,061 | 5,059,856 | ||||||||||||
Income from operations |
290,496 | 1,482,142 | 2,726,120 | 2,022,248 | ||||||||||||
Net income |
252,495 | 997,684 | 1,639,409 | 1,314,131 | ||||||||||||
Basic net income per common share |
0.07 | 0.27 | 0.43 | 0.32 | ||||||||||||
Diluted net income per common share |
0.06 | 0.25 | 0.39 | 0.30 | ||||||||||||
Basic weighted average common shares
outstanding |
3,604,555 | 3,653,501 | 3,808,809 | 4,065,489 | ||||||||||||
Diluted weighted average common shares
outstanding |
3,960,138 | 4,040,282 | 4,198,742 | 4,405,220 | ||||||||||||
2004 |
||||||||||||||||
Revenue |
$ | 39,168,733 | $ | 43,708,119 | $ | 42,103,802 | $ | 41,851,010 | ||||||||
Gross profit |
2,463,975 | 1,602,522 | 936,807 | 1,964,486 | ||||||||||||
Income (loss) from operations |
791,456 | 182,985 | (657,160 | ) | 140,670 | |||||||||||
Net income (loss) |
436,663 | 38,437 | (427,085 | ) | 525,624 | |||||||||||
Basic net income (loss) per common share |
0.12 | 0.01 | (0.12 | ) | 0.15 | |||||||||||
Diluted net income (loss) per common share |
0.12 | 0.01 | (0.12 | ) | 0.14 | |||||||||||
Basic weighted average common shares
outstanding |
3,601,250 | 3,601,250 | 3,601,250 | 3,601,250 | ||||||||||||
Diluted weighted average common shares
outstanding |
3,754,754 | 3,742,934 | 3,601,250 | 3,887,900 | ||||||||||||
59
Table of Contents
Item 9. Changes in and Disagreements with Accountants on Accounting and Financial Disclosure
None.
Item 9A. Controls and Procedures
An evaluation as of the end of the period covered by this report was carried out under the
supervision and with the participation of the Company’s management, including its Chief Executive
Officer and Chief Financial Officer, of the effectiveness of the design and operation of the
Company’s disclosure controls and procedures (as defined in Rule 13a-15(e) or 15d-15(e) under the
Securities Exchange Act of 1934). Based upon that evaluation, the Chief Executive Officer and Chief
Financial Officer concluded that those disclosure controls and procedures were effective in
providing reasonable assurance that information required to be disclosed by the Company in the
reports that it files or submits under the Securities Exchange Act of 1934 is recorded, processed,
summarized and reported within the time periods specified in the Commission’s rules and forms. In
addition, there has been no change in the Company’s internal control over financial reporting (as
defined in Rule 13a-15(f) and 15d-15(f) under the Securities Exchange Act of 1934) that occurred
during the period covered by this report that has materially affected, or is reasonably likely to
materially affect, the Company’s internal control over financial reporting.
It should be noted that any system of controls, however well designed and operated, can
provide only reasonable, not absolute, assurance that the objectives of the system are met. In
addition, the design of any control system is based in part upon certain assumptions about the
likelihood of future events. Because of these and other inherent limitations of control systems,
there can be no assurance that any design will succeed in achieving its stated goals under all
potential future conditions, regardless of how remote.
Item 9B. Other Information
None.
PART III
Item 10. Directors, Executive Officers and Corporate Governance
The information required by Item 10 is incorporated herein by reference to the information
contained under the headings “Election of Directors” and “Executive Officers” as set forth in our
definitive proxy statement for our 2006 annual meeting of shareholders.
Item 11. Executive Compensation
The information required by Item 11 relating to our directors is incorporated herein by
reference to the information contained under the heading “Compensation of Directors” and the
information relating to our executive officers is incorporated herein by reference to the
information contained under the heading “Executive Compensation” as set forth in our definitive
proxy statement for our 2006 annual meeting of shareholders.
| Item 12. Security Ownership of Certain Beneficial Owners and Management and Related Stockholder Matters |
The information required by Item 12 is incorporated herein by reference to the information
contained under the headings “Election of Directors,” “Equity Compensation Plan Information,” and
“Security Ownership of Certain Beneficial Owners and Management” as set forth in our definitive
proxy statement for our 2006 annual meeting of shareholders.
60
Table of Contents
Item 13. Certain Relationships and Related Transactions, and Director Independence
The information required by Item 13 is incorporated herein by reference to the information
contained under the heading “Certain Relationships and Related Transactions” as set forth in our
definitive proxy statement for our 2006 annual meeting of shareholders.
Item 14. Principal Accounting Fees and Services
The information required by Item 14 is incorporated herein by reference to the information
contained under the heading “Disclosure of Audit and Non-Audit Fees” as set forth in our definitive
proxy statement for our 2006 annual meeting of shareholders.
PART IV
Item 15. Exhibits and Financial Statement Schedules
(a) (1) Financial Statements
See Item 8 of Part II hereof.
(2) Financial Statement Schedules
See Schedule below and Item 8 of Part II hereof.
Schedule of Valuation and Qualifying Accounts:
In Thousands
| Balance at | Charged to | Balance at | ||||||||||||||
| Beginning | Expense | Ending | ||||||||||||||
| Description | of Year | Account | Deductions | of Year | ||||||||||||
Year ended December 31, 2004 |
||||||||||||||||
Allowance for doubtful accounts |
$ | 710 | $ | 278 | $ | (380 | ) | $ | 608 | |||||||
Allowance for potentially obsolete or
slow moving inventory |
$ | 1,186 | $ | — | $ | (899 | ) | $ | 287 | |||||||
Year ended December 31, 2005 |
||||||||||||||||
Allowance for doubtful accounts |
$ | 608 | $ | (207 | ) | $ | (75 | ) | $ | 326 | ||||||
Allowance for potentially obsolete or
slow moving inventory |
$ | 287 | $ | — | $ | (43 | ) | $ | 244 | |||||||
Year ended December 31, 2006 |
||||||||||||||||
Allowance for doubtful accounts |
$ | 326 | $ | 126 | $ | (57 | ) | $ | 395 | |||||||
Allowance for potentially obsolete or
slow moving inventory |
$ | 244 | $ | (44 | ) | $ | — | $ | 200 | |||||||
(3) Exhibits
| Exhibit | ||
| No. | Title | |
3.01
|
Articles of Incorporation and Amendments thereto of the Registrant (1) | |
3.02
|
Bylaws of the Registrant (1) | |
3.03
|
Bylaws of the Registrant Effective October 20, 1995 (1) | |
3.04
|
Bylaws of the Registrant Effective April 28, 1997 (20) | |
3.05
|
Bylaws of the Registrant Effective September 13, 2004 (15) | |
61
Table of Contents
| Exhibit | ||
| No. | Title | |
3.06
|
Bylaws of the Registrant Effective February 5, 2007 (16) | |
3.07
|
Certificate of Designation of Series a Participating Preferred Stock Effective February 13, 2007 (17) | |
4.1
|
Shareholder Rights Plan Effective February 13, 2007 (18) | |
10.1
|
Form of Indemnification Agreement with entered into by the Registrant with its Directors and executive officers (2) | |
10.2
|
Employment Agreement with Bradley E. Larson * | |
10.3
|
Employment Agreement with Kenneth D. Nelson * | |
10.4
|
Employment Agreement with Alan A. Terril * | |
10.5
|
Property Lease and Aggregate Supply Agreement with Sun State Rock & Materials Corp. (7) | |
10.6
|
Property Lease and Aggregate Supply Agreement with Clay R. Oliver d.b.a. Oliver Mining Company (7) | |
10.7
|
Office Lease Agreement (20) | |
10.8
|
Amendment to Office Lease Agreement of the Registrant (9) | |
10.9
|
Amendment to Office Lease Agreement of the Registrant (9) | |
10.10
|
General Agreement of Indemnity between the Registrant and Liberty Mutual Insurance Company (3) | |
10.11
|
Settlement Agreement and Release between the Registrant and New Mexico Department of Transportation (11) | |
10.12
|
Promissory Note with Nevada State Bank (12) | |
10.13
|
Promissory Note with Nevada State Bank (12) | |
10.14
|
Master Lease Agreement with The CIT Group/Equipment Financing, Inc. (7) | |
10.15
|
Master Lease Agreement with The CIT Group/Equipment Financing, Inc. (7) | |
10.16
|
Master Security Agreement with The CIT Group/Equipment Financing, Inc. (7) | |
10.17
|
Master Security Agreement with The CIT Group/Equipment Financing, Inc. (7) | |
10.18
|
Master Lease Agreement with The CIT Group/Equipment Financing, Inc. (7) | |
10.19
|
Master Lease Agreement with The CIT Group/Equipment Financing, Inc. (13) | |
10.20
|
Master Lease Agreement with The CIT Group/Equipment Financing, Inc. (12) | |
10.21
|
Revolving Loan Agreement with The CIT Group/Equipment Financing, Inc. (7) | |
10.22
|
Amended and Restated Revolving Loan Agreement with The CIT Group/Equipment Financing, Inc. (8) | |
10.23
|
Revolving Loan Agreement with The CIT Group/Equipment Financing, Inc. (8) | |
10.24
|
Amendment No. 1 to Restated and Amended Revolving Loan Agreement with The CIT Group/Equipment Financing, Inc. (20) | |
10.25
|
Amendment No. 2 to Restated and Amended Revolving Loan Agreement with The CIT Group/Equipment Financing, Inc. (20) | |
10.26
|
Renewal and Amendment of Amended and Restated Revolving Loan Agreement with The CIT Group/Equipment Financing, Inc. (5) | |
10.27
|
Renewal and Amendment of Revolving Loan Agreement with The CIT Group/Equipment Financing, Inc. (5) | |
62
Table of Contents
| Exhibit | ||
| No. | Title | |
10.28
|
Amendment of Amended and Restated Revolving Loan Agreement with The CIT Group/Equipment Financing, Inc. (13) | |
10.29
|
Amendment of Revolving Loan Agreement with The CIT Group/Equipment Financing, Inc. (13) | |
10.30
|
Line of Credit Agreement with GMAC Financial Services (10) | |
10.31
|
Line of Credit Agreement with Ford Motor Credit Company (10) | |
10.32
|
Commitment letter from DaimlerChrysler Services (14) | |
10.33
|
Master Lease Agreement with Wells Fargo Equipment Finance, Inc. (14) | |
10.34
|
Employment Agreement with David D. Doty (19) | |
10.35
|
Office Lease Agreement * | |
10.36
|
Amendment to Office Lease Agreement of the Registrant * | |
14.1
|
Code of Ethics for Senior Management (11) | |
21
|
Subsidiaries of the Registrant (1) | |
23
|
Consent of Independent Auditors * | |
31.1
|
Certification of Chief Executive Officer pursuant to Section 302 of the Sarbanes-Oxley Act of 2002. * | |
31.2
|
Certification of Chief Financial Officer pursuant to Section 302 of the Sarbanes-Oxley Act of 2002. * | |
32
|
Certifications of Chief Executive Officer and Chief Financial Officer pursuant to 18 U.S.C. Section 1350, as adopted pursuant to Section 906 of the Sarbanes-Oxley Act of 2002. * | |
| (1) | Incorporation by reference to the Company’s Registration Statement on Form S-1, File Number 33-87750 declared effective on October 16, 1995 | |
| (2) | Previously filed as an Exhibit with the same Exhibit number to the Company’s Form 8-K Current Report dated March 9, 2007 | |
| (3) | Incorporated by reference to the Company’s June 30, 2002 Form 10-Q | |
| (4) | Incorporated by reference to the Company’s September 30, 2002 Form 10-Q | |
| (5) | Incorporated by reference to the Company’s December 31, 2002 Annual Report on Form 10-K | |
| (6) | Incorporated by reference to the Company’s December 31, 1998 Annual Report on Form 10-K | |
| (7) | Incorporated by reference to the Company’s December 31, 2000 Annual Report on Form 10-K | |
| (8) | Incorporated by reference to the Company’s September 30, 2001 Form 10-Q | |
| (9) | Incorporated by reference to the Company’s June 30, 2003 Form 10-Q | |
| (10) | Incorporated by reference to the Company’s September 30, 2003 Form 10-Q | |
| (11) | Incorporated by reference to the Company’s December 31, 2003 Annual Report on Form 10-K | |
| (12) | Incorporated by reference to the Company’s June 30, 2004 Form 10-Q | |
| (13) | Incorporated by reference to the Company’s March 31, 2003 Form 10-Q | |
| (14) | Incorporated by reference to the Company’s March 31, 2004 Form 10-Q | |
| (15) | Previously filed as an Exhibit with the same Exhibit number to the Company’s Form 8-K Current Report dated September 13, 2004 | |
| (16) | Previously filed as Exhibit 3.2 to the Company’s Form 8-K Current Report dated February 9, 2007 |
63
Table of Contents
| (17) | Previously filed as Exhibit 3.1 to the Company’s Form 8-K Current Report dated February 14, 2007 | |
| (18) | Previously filed as an Exhibit with the same Exhibit number to the Company’s Form 8-K Current Report dated February 14, 2007 | |
| (19) | Previously filed without exhibit to the Company’s Form 8-K Current Report dated November 7, 2006 | |
| (20) | Incorporated by reference to the Company’s December 31, 2001 Annual Report on Form 10-K | |
| * | Filed herewith. |
64
Table of Contents
SIGNATURES
Pursuant to the requirements of Section 13 or 15(d) of the Securities Exchange Act of 1934,
the registrant has duly caused this report to be signed on its behalf by the undersigned, thereunto
duly authorized.
| MEADOW VALLEY CORPORATION | ||||
| /s/ Bradley E. Larson
|
||||
| President and Chief Executive Officer | ||||
| (Principal Executive Officer) | ||||
| Date: March 30, 2007 |
POWER OF ATTORNEY
KNOW ALL MEN BY THESE PRESENTS, that each person whose signature appears below constitutes and
appoints BRADLEY E. LARSON and DAVID D. DOTY, and each of them, his true and lawful
attorneys-in-fact and agents, with full power of substitution and resubstitution for him in his
name, place and stead, in any and all capacities, to sign any and all amendments to this Form 10-K,
and to file the same, with all exhibits thereto, and other documents in connection therewith with
the Securities and Exchange Commission, granting onto said attorneys-in-fact and agents, and each
of them, full power and authority to do and perform each and every act and thing requisite and
necessary to be done in and about the premises as fully and to all intent and purposes as he might
or could do in person hereby ratifying and confirming all that said attorneys-in-fact and agents,
or his substitute or substitutes, may lawfully do or cause to be done by virtue hereof.
Pursuant to the requirements of the Securities Exchange Act of 1934, this report has been
signed below by the following persons on behalf of the registrant and in the capacities and on the
dates indicated.
/s/ Bradley E. Larson
|
/s/ Don A. Patterson
|
|||
Director, President and Chief Executive Officer
|
Director | |||
Date: March 30, 2007
|
Date: March 30, 2007 | |||
/s/ Kenneth D. Nelson
|
/s/ Charles E. Cowan
|
|||
Director, Chief Administrative Officer and
|
Director | |||
Vice President
|
Date: March 30, 2007 | |||
Date: March 30, 2007 |
||||
/s/ Charles R. Norton
|
/s/ David D. Doty
|
|||
Director
|
Chief Financial Officer, Treasurer, Secretary and | |||
Date: March 30, 2007
|
Principal Financial and Accounting Officer | |||
| Date: March 30, 2007 |
65